Capital Improvement Program

Capital Improvement Program Overview

Photo of MPWD staff on an active construction job site.

The Mid-Peninsula Water District (MPWD) has completed several strategic projects over the past few years, each of them building upon the other, in order to best consider the entire MPWD system and its capital infrastructure rehabilitation and improvements needs, including:

  • Construction standards and specifications;
  • Water hydraulic modeling, comprehensive system analysis, and capital program development;
  • Water capacity charges update (including water demand offset fees); and
  • Water financial plan and rate study (including a 2016 update).

Why Is a Capital Improvement Program Important?

  • It allows for a systematic evaluation of all potential projects at the same time in a prioritized order.
  • It allows for grouping of projects for construction, which will reduce overall program cost.
  • It aids in the preservation of the MPWD’s infrastructure while ensuring the efficient use of public funds.
  • It provides sound information to the Board of Directors and its customers on the infrastructure needs of the MPWD.
  • Through its development, it allows an opportunity to foster cooperation among staff, management, and the District Engineer.
  • It is a reinvestment of ratepayer dollars back into the water system, which is good financial stewardship.

Construction Standards and Specifications

Operations staff, the District Engineer, and management teamed up and revised its construction standards and specifications, which was important not only for consistent construction application throughout the MPWD system for operations and maintenance, but also in preparation for a major capital improvement program and for development activity. The MPWD standards can be downloaded here.


Water Hydraulic Modeling and Comprehensive System Analysis & CIP

In preparation of a meaningful capital program, Operations staff, the District Engineer, and management systematically reviewed the MPWD’s infrastructure and developed a water hydraulic model to identify system deficiencies and rehabilitation areas. This was an 18-month process and one in which institutional knowledge of the MPWD system blended with engineering know-how and management experience resulting in the development of a comprehensive roster of needed capital projects. A distribution system analysis was performed and a report generated by the District Engineer for each capital project, including an engineering cost estimate (2015 dollars). Approximately 90 capital projects were identified, totaling over $50 million (2015 dollars). Operations staff developed pertinent criteria for evaluating the projects for prioritization, which resulted in the MPWD’s proposed CIP. Download the complete Comprehensive System Analysis & CIP here.

Photo of construction crews on an active job site.

A 5-Year CIP totaling $20 million was developed after the projects were ranked and discussed with the Board of Directors during 2015 and 2016. It was approved on May 26, 2016.

The water hydraulic model is a valuable tool for MPWD operations and maintenance analyses, development assessments and fire flow reviews, and is well used and maintained to keep it resourceful.


Water Capacity Charges Update

The MPWD hired an independent public finance consultant, Bartle Wells Associates, to work with staff for review and update of the MPWD’s development impact fees and structure. That nearly 9-month process was thoroughly vetted by the Board of Directors to ensure transparent stakeholder and customer participation and input. The result was a Water Capacity Charges Update dated March 20, 2015 that was adopted by the Board of Directors per Ordinance No. 112 dated April 23, 2015.

Not only were Water Capacity Charges updated for new development requiring a “buy-in” to the MPWD system for its added service impact, but the MPWD also created water demand offset fees to manage the new demand within its available regional water system supply from the San Francisco Public Utilities Commission (SFPUC). This is in addition to the new development requirements to comply with current building codes requiring high efficiency water fixtures. Dependent upon the economy and local development within the MPWD service area, these revenue sources supplement funding available for capital projects and water conservation/education programs and public outreach.


Water Financial Plan and Rate Study and 2016 Update

The MPWD updated its water financial plan and reviewed its rates and structure, again with the assistance of Bartle Wells & Associates. A rate workshop was held on March 26, 2015. A water financial plan and rate study was presented to the Board of Directors on May 26, 2015, including phased increases to the monthly fixed system charges and within the tiered structure. Further provisions adopted were “pass-through” of additional increases by the SFPUC to projected wholesale water rates, and emergency water shortage rates should the MPWD experience a significant decrease in its water commodity revenues as a result of water use reductions due to a drought. Download the plan and rate study here.

Photo of construction crews on an active job site.

Here is public notice for the water rate hearing conducted on June 25, 2015, including the proposed water rate increases over five (5) years, beginning July 1, 2015.

Water rate increases were adopted by the Board of Directors on June 25, 2105, per Ordinance No. 114 and its Exhibit A – Schedule of Rates and Fees.

In Fiscal Year (FY) 2015/2016, water conservation efforts resulted in lower revenue receipts. Therefore, the MPWD contracted with Bartle Wells & Associates to review and update its 2015 financial plan and rate study in order to adequately prepare for the FY 2016/2017 budget process. On April 28, 2016, the Board of Directors received the Bartle Wells & Associates updated financial and rate report dated April 24, 2016.

Cash flow projections were decreased as a result of the reduced water sales (drought impacts), and the water rate increase approved in 2015 was recommended for implementation. The potential for debt financing for the MPWD CIP was analyzed and it was concluded that an annual debt service payment of $1,045,000 could be achieved, even with the reduced cash flow projections. Finally, excess revenues were forecasted resulting in sufficient coverage required for debt financing.

  • Late October, 2023

    Late October, 2023

    Old County Road Water Main Improvement Project

    Click on map at right for expanded view

    Contractor will begin ground breaking on Old County Road, Ralston Avenue, and F Street in late October, 2023. Phase 1 construction will occur along OCR from Ralston Avenue (on the north end) to F Street (on the south end), and approximately 450 feet along Ralston Avenue between OCR and Elmer Street. Construction is expected to continue through September, 2024.

    Daily lane closures along OCR will occur between 8:00 am to 5:00 pm and along Ralston Avenue between 9:00 am to 3:00 pm, except for holidays and weekends. Motorists can expect one lane traffic control, road closures, detours, and possible 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents, businesses, pedestrians, and emergency vehicles will be maintained at all times. Should you have any questions, please contact the Construction Hotline at 650-477-5462

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit. We apologize for the inconvenience and we appreciate your cooperation. For more information about the OCR Water Main Improvement Project, please click here.


Archived Advisories

  • October 8, 2021 +-

    October 8, 2021

    El Camino Real Water Main Improvement Project

    Click on map at right for expanded view

    Nighttime Construction: Lane and street closures should be expected at the intersection of El Camino Real and Waltermire Street on Friday, October 8, 2021 from 9:00 pm and 5:00 am. Traffic to and from Safeway will be maintained throughout the night. Should the intersection be closed, detour route(s) and signage will be provided to motorists on the local streets. Impact to traffic is expected to be minor at nighttime. Work is on southbound direction only.

    Nighttime construction is chosen to minimize traffic impacts to local businesses, especially the Safeway Store on Waltermire Street. Access for local residents, businesses, pedestrians, and emergency vehicles will be maintained at all times. Should you have any questions, please contact the Construction Hotline at 650-222-4360

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit. We apologize for the inconvenience and we appreciate your cooperation. For more information about the ECR Water Main Improvement Project, please click here


  • October 1, 2021 +-

    October 1, 2021

    El Camino Real Water Main Improvement Project

    Click on map at right for expanded view

    Nighttime Construction: Lane and street closures should be expected at the intersection of El Camino Real and Emmett Avenue on Friday, October 1, 2021 from 9:00 pm and 5:00 am. Traffic to and from Safeway will be maintained throughout the night. Should the intersection be closed, detour route(s) and signage will be provided to motorists on the local streets. Impact to traffic is expected to be minor at nighttime. Work is on southbound direction only.

    Nighttime construction is chosen to minimize traffic impacts to local businesses, especially the Safeway Store on Emmett Avenue. Access for local residents, businesses, pedestrians, and emergency vehicles will be maintained at all times. Should you have any questions, please contact the Construction Hotline at 650-222-4360

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit. We apologize for the inconvenience and we appreciate your cooperation. For more information about the ECR Water Main Improvement Project, please click here


  • June 14, 2021 +-

    June 14, 2021

    El Camino Real Water Main Improvement Project

    Click on map at right for expanded view

    Contractor will commence installation of the new 8-inch DIP on the southbound only El Camino Real (ECR) on Monday, June 14, 2021. Phase 1 construction will include right lane closure between Ruth Road and Middle Road and is expected to continue through November, 2021.

    Right lane closure will occur daily between 9:00 am to 3:00 pm, except for holidays and weekends. Traffic control signs will be in place to guide motorists. Motorists can expect one-lane traffic control and possible 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents, businesses, pedestrians, and emergency vehicles will be maintained at all times. Should you have any questions, please contact the Construction Hotline at 650-222-4360

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit. We apologize for the inconvenience and we appreciate your cooperation. For more information about the ECR Water Main Improvement Project, please click here


  • May 3-7, 2021 +-

    May 3-7, 2021

    El Camino Real Water Main Improvement Project

    Click on map at right for expanded view

    Contractor will continue utility potholing operation on the southbound only El Camino Real (ECR) the first week of May 2021, and commence saw cutting of the existing asphalt concrete along the alignment of the new waterline. Phase 1 construction will include right lane closure between Ruth Road and Middle Road and is expected to continue through November, 2021.

    Right lane closure will occur daily between 9:00 am to 3:00 pm, except for holidays and weekends. Traffic control signs will be in place to guide motorists. Motorists can expect one lane traffic control and possible 15-minute delays through this area. However, significant impacts to traffic are not expected during this week's operations. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents, businesses, pedestrians, and emergency vehicles will be maintained at all times. Should you have any questions, please contact the Construction Hotline at 650-222-4360

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit. We apologize for the inconvenience and we appreciate your cooperation. For more information about the ECR Water Main Improvement Project, please click here


  • No Traffic Delays Expected Until May +-

    No Traffic Delays Expected Until May

    El Camino Real Water Main Improvement Project

    Due to a project delay, construction along the southbound El Camino Real are not expected to resume until the second week of May. Please visit back for further updates. Thank you.

    Should you have any questions, please contact the Construction Hotline at 650-222-4360

  • March 8-12, 2021 +-

    March 8-12, 2021

    El Camino Real Water Main Improvement Project

    Click on map at right for expanded view

    Contractor will continue ground breaking on the southbound-only El Camino Real (ECR) with right lane closures between Ruth Road and Middle Road. Minor impact on traffic is expected. The left lane will remain available for traffic.

    Any lane closures will occur daily between 9:00 am to 3:00 pm, except for holidays and weekends. Motorists can expect one-lane traffic control and possible 15-minute delays through this area. Construction is expected to continue through November, 2021. Please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents, businesses, pedestrians, and emergency vehicles will be maintained at all times. Should you have any questions, please contact the Construction Hotline at 650-222-4360

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit. We apologize for the inconvenience and we appreciate your cooperation. For more information about the ECR Water Main Improvement Project, please click here.

  • March 1-5, 2021 +-

    March 1-5, 2021

    El Camino Real Water Main Improvement Project

    Click on map at right for expanded view

    Contractor will begin ground breaking on the southbound only El Camino Real (ECR) the first week of March, 2021. Phase 1 construction will include right lane closure between Ruth Road and Middle Road. The left lane will remain available for traffic. Construction is expected to continue through November, 2021.

    Lane closure will occur daily between 9:00 am to 3:00 pm, except for holidays and weekends. Motorists can expect one lane traffic control and possible 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents, businesses, pedestrians, and emergency vehicles will be maintained at all times. Should you have any questions, please contact the Construction Hotline at 650-222-4360

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit. We apologize for the inconvenience and we appreciate your cooperation. For more information about the ECR Water Main Improvement Project, please click here
  • May 6, 2020 +-

    May 6, 2020

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    Contractor will be striping the road on Notre Dame Avenue from Terrace Drive up to Valley View Avenue. Road work is scheduled for Wednesday, May 6.

    During construction hours of 8:00 am to 5:00 pm, motorists can expect one lane traffic control and minimal delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • May 6, 2020 +-

    May 6, 2020

    Malcolm Ave. Improvement Update

    Click on map at right for expanded view

    Contractor will be striping the road on Malcolm Avenue between Ruth Avenue and Anita Avenue on Wednesday, May 6.

    During construction hours of 8:00 am to 5:00 pm, expect temporary street closures and minimal delays on Ruth Avenue and Anita Avenue near those intersections. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • April 27-29 +-

    April 27-29

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    Contractor will be slurry sealing the asphalt on Notre Dame Avenue from Terrace Drive up to Valley View Avenue, with slurry seal extending 20-30 feet into the streets that intersect Notre Dame Avenue along the way (Folger Drive, Manzanita Avenue, Middle Road, Valley View Avenue). Road work is scheduled for Monday, April 27 through Wednesday, April 29.

    During construction hours of 8:00 am to 5:00 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • April 27-28 +-

    April 27-28

    Tahoe Drive Area Improvements Update (Yosemite, Muir, Tioga, Bryce)

    Click on map at right for expanded view

    Contractor will be slurry sealing the asphalt on Bryce Court, Muir Way, and Tioga Way from Monday, April 27 through Tuesday, April 28.

    During construction hours of 8:00 am to 5:00 pm, expect temporary street closures as well as possible delays on Yosemite Drive and Tahoe Drive near those intersections. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • April 28 +-

    April 28

    Malcolm Ave. Improvement Update

    Click on map at right for expanded view

    Contractor will be slurry sealing the asphalt on Malcolm Avenue between Ruth Avenue and Anita Avenue on Tuesday, April 28.

    During construction hours of 8:00 am to 5:00 pm, expect temporary street closures as well as possible delays on Ruth Avenue and Anita Avenue near those intersections. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • February 17-21 +-

    February 17-21

    Tahoe Drive Area Improvements Update (Yosemite, Muir, Tioga)

    Click on map at right for expanded view

    The contractor will slurry seal the streets and restore street markings. No construction work will occur on Presidents Day, Monday, February 17.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and possible delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit. We apologize for the inconvenience and we appreciate your cooperation.

  • February 5 +-

    February 5

    Tahoe Drive Area Improvements Update (Yosemite, Muir, Tioga)

    Click on map at right for expanded view

    The contractor is scheduled to be grinding and paving Tioga Way, Muir Way, Tahoe Drive, and Bryce Court on Wednesday, February 5. Contractor will be posting ‘no parking’ signs on Monday.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and possible delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit. We apologize for the inconvenience and we appreciate your cooperation.

  • February 3-7 +-

    February 3-7

    Zone 5 (Altura/Desvio/Solana) Fire Hydrant Upgrades

    Click on map at right for expanded view

    This project will install 4 new fire hydrants and replace 3 existing fire hydrants in the area. The contractor will be working on Altura Way February 3-4 replacing two fire hydrants.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and possible delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428


    It is recommended that affected motorists make necessary accommodations. We apologize for the inconvenience and we appreciate your cooperation.

  • January 27-31 +-

    January 27-31

    Cliffside Court Improvement Project

    Click on map at right for expanded view

    The contractor will return to Cliffside Court January 27-31 working on service line connections.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and possible delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428


    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • January 20-24 +-

    January 20-24

    Cliffside Court Improvement Project

    Click on map at right for expanded view

    The contractor will be working on Cliffside Court January 21-24 with service line connections. No work will be performed on Monday, January 20 in observance of Martin Luther King Jr. Day.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and possible delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428


    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • January 13-17 +-

    January 13-17

    Cliffside Court Improvement Project

    Click on map at right for expanded view

    The contractor will be back onsite Monday, January 13, on Cliffside Court and will be excavating the roadway to replace the service lines and blow-offs at the end of Cliffside Court.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and possible delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428


    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • December 23 – January 3 +-

    December 23 – January 3

    Cliffside Court Improvement Project

    Click on map at right for expanded view

    The contractor will return to the job site on January 6.

  • December 16-20 +-

    December 16-20

    Cliffside Court Improvement Project

    Click on map at right for expanded view

    The contractor will be working on Cliffside Court laying out the new water service connections.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and possible delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428


    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • November 25-29 +-

    November 25-29

    Tahoe Drive Area Improvements Update (Yosemite, Muir, Tioga)

    Click on map at right for expanded view

    The contractor will be working on Yosemite Drive / Muir Way and Muir Way / Tahoe Drive on November 22 getting ready for the following week. On November 25, the contractor will be working on Tahoe Drive between Lassen Drive and Bryce Court doing a water main connection.

    No work will be performed on Thursday, November 28 – Friday, November 29 in observation of the Thanksgiving holiday.

    Work will resume in the area on Monday, December 2 on Tahoe Drive.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and possible delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • November 18-22 +-

    November 18-22

    Tahoe Drive Area Improvements Update (Yosemite, Muir, Tioga)

    Click on map at right for expanded view

    The contractor will be working on Tahoe Drive and Bryce Court.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and possible delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • November 11-15 +-

    November 11-15

    Tahoe Drive Area Improvements Update (Yosemite, Muir, Tioga)

    Click on map at right for expanded view

    The contractor is currently working on Muir Way running service connections, extending into the week of November 11-15, and planning to do a tie-in connection on Tioga Way and/or Muir Way for the week of November 11-15.

    The contractor will be working on Yosemite Drive and Muir Way on November 15 connecting the new water main.

    No work is scheduled for Monday, November 11 in observance of Veterans Day.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • November 4-8 +-

    November 4-8

    Tahoe Drive Area Improvements Update (Yosemite, Muir, Tioga)

    Click on map at right for expanded view

    The contractor will be working on the service connections on Tioga Way and Muir Way.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • October 31-November 4 +-

    October 31-November 4

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    The contractor is currently paving the service laterals on Notre Dame Avenue this week and possibly the beginning of November 4. The contractor would like to complete all the asphalt concrete work on Notre Dame Avenue from Terrace Drive to Valley View Avenue.

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    We apologize for the inconvenience and we appreciate your cooperation.

  • October 28-November 1 +-

    October 28-November 1

    Tahoe Drive Area Improvements Update (Yosemite, Muir, Tioga)

    Click on map at right for expanded view

    The contractor will be working on service laterals on Bryce Court, Muir Way, and working towards Tioga Way.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the Associate Engineer Victor Fung: 925-353-0507

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • October 24-28 +-

    October 24-28

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    The contractor will be grinding and paving Notre Dame Avenue from Terrace Drive to Valley View Avenue Thursday, October 24 - Monday, October 28.

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the Associate Engineer Victor Fung: 925-353-0507

    We apologize for the inconvenience and we appreciate your cooperation.

  • October 21-23 +-

    October 21-23

    Tahoe Drive Area Improvements Update (Yosemite, Muir, Tioga)

    Click on map at right for expanded view

    The contractor is working on Muir Way working towards Tahoe Drive excavating a trench to install a new water main. Expect delays and construction activities on Yosemite Drive and Tahoe Drive. Work on Muir Way and Tahoe Drive is expected to finish by October 23.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the Associate Engineer Victor Fung: 925-353-0507

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • October 21-25 +-

    October 21-25

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    • The contractor is returning to Notre Dame Avenue to work on the final trench pavement.
    • Paving on Notre Dame Avenue is scheduled for Thursday, October 24 - Friday, October 25.

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the Associate Engineer Victor Fung: 925-353-0507

    We apologize for the inconvenience and we appreciate your cooperation.

  • October 15-18 +-

    October 15-18

    Tahoe Drive Area Improvements Update (Yosemite, Muir, Tioga)

    Click on map at right for expanded view

    The contractor is working on Yosemite Drive and Tioga Way excavating a trench to install a new water main. Monday, October 14 is Columbus Day. It is an observed holiday by MPWD and no work will be performed. Work will continue Tuesday, October 15 through Friday, October 18. Expect delays on Yosemite Drive and arterial streets.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the Associate Engineer Victor Fung: 925-353-0507

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • October 7-11 +-

    October 7-11

    Tahoe Drive Area Improvements Update (Yosemite, Muir, Tioga)

    Click on map at right for expanded view

    Beginning October 7, the contractor will be working at the intersections of Yosemite Drive / Muir Way and Yosemite Drive / Tioga Way. A small crew will be saw-cutting the sidewalk and pavement. "No Parking" signs have been posted.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • October 7-11 +-

    October 7-11

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    • The contractor continues to work on the service laterals near Valley View Avenue. Beginning October 7, the contractor will be focusing at the intersection of Notre Dame Avenue and Valley View Avenue getting ready to connect the new water main to the system.

    • Expect delays on Valley View Ave the entire week of October 7-11.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • September 25 – October 4 +-

    September 25 – October 4

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    • The contractor will be working at the intersection of Terrace Drive and Notre Dame Avenue on Wednesday and Thursday September 25 and 26, respectively.
    • On Friday September 27, the contractor will be working in front of 1721 and 1723 Valley View Avenue replacing a gate valve.
    • Beginning the week of September 30 through October 4, the contractor will continue to work on the service laterals from North Road to Valley View Avenue.
    • During the week of September 30, expect a few more delays on Valley View Avenue.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • September 23-27 +-

    September 23-27

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    The contractor will be working at the intersection of Terrace Drive on Thursday, September 19 – Friday, September 20, and on Middle Road Friday, September 20. Beginning the week of September 23, the contractor will continue to work on the service connections from North Road to Valley View Avenue.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • September 16-20 +-

    September 16-20

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    The contractor finished the 8" water main installation on Notre Dame Avenue. Beginning the week of September 16, the contractor will be working on the service connections from North Road to Valley View Avenue. The contractor will be working on Notre Dame Avenue and Terrace Drive getting ready for water main connection.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • September 9-13 +-

    September 9-13

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    The contractor will be finishing the installation of the 8" water line on Notre Dame Ave at Valley View Avenue by the end of September 6. Staring on September 9, the contractor will be excavating a cross the street of Notre Dame Avenue to install new service connections from Manzanita Avenue to Valley View Avenue. The contractor will also begin to mobilize and start to saw-cut the roadway on Muir Way and Tioga Way for the new 8" water main.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • September 2-6 +-

    September 2-6

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    This week, the contractor continues to excavate a trench to install an 8" water main. The contractor is working north of North Avenue near 1606 Notre Dame Avenue. No work will be performed on Monday September 2 in observance of Labor Day. Work will resume on Tuesday, September 3. We anticipate reaching Valley View Avenue by September 6.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • August 26-30 +-

    August 26-30

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    Contractor continues to work diligently on Notre Dame Avenue at the intersection of Notre Dame Place the rest of the week. The Contractor will continue to work towards Manzanita Avenue on Monday 8/26 with the excavation and installation of the 8” water main.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • August 19-23 +-

    August 19-23

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    Contractor is completing the water main connections at the intersection of Notre Dame Avenue at Folger Avenue and at Notre Dame Place through the week of August 16. Beginning on Monday, August 19, the contractor will begin excavating the trench to install an 8" water line starting at the intersection of Terrace Drive and Notre Dame Avenue and continuing north towards Folger Drive.

    During construction hours of 8:00 am to 4:30 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • August 12-16 +-

    August 12-16

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    Contractor will continue to pothole on August 8 and 9 on Notre Dame Avenue from Folger Avenue to Middle Road. Beginning the week of August 12, contractor will begin saw cutting the roadway for the new water main beginning on Terrance Drive.

    During construction hours of 8:00 am to 5:00 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • July 29 - August 9 +-

    July 29 - August 9

    Notre Dame Water Main Project Update

    Click on map at right for expanded view

    This is the first week of construction. The contractor is scheduled to mobilize on Monday using their staging yard on Folger Drive. They will be bringing in equipment and material to this site. During the latter part of the week construction will start at the intersection of Notre Dame Avenue and Terrace Drive and continue north towards Valley View Avenue. Motorists are advised to avoid this area. During construction hours of 8:00 am to 5:00 pm, motorists can expect one lane traffic control and up to 15-minute delays through this area. In addition, please be aware of heavy equipment, construction personnel, and increased noise levels. Access for local residents and emergency vehicles will be maintained at all times. Should you have any questions, please contact the District Inspector Rick Bisio: 650-222-0428

    It is recommended that affected motorists make necessary accommodations or use alternate routes as they see fit.

    We apologize for the inconvenience and we appreciate your cooperation.

  • CIP Updates - January 25, 2024

    Old County Road / Ralston Avenue Water Main Improvements

    As of December 31, 2023, C2R Engineering (C2R) successfully finished all work involved with installing the 12" water main along Harbor Blvd. All the services were installed, and the old water main was successfully abandoned. Street and concrete sidewalk restoration was also completed, including street slurry sealing and replacing the traffic striping and markings. Contractor has progressed work ahead of the baseline schedule with approximately 483 feet of new pipe installed with 185 of 220 Working Days remaining.

    Image of constructions works on the OCR project during night time operations
    Image of constructions works on the OCR project during night time operations
  • CIP Updates - December 2023

    Old County Road / Ralston Avenue Water Main Improvements

    The Notice to Proceed was issued on November 6, 2023, and Contractor has since progressed field work. Contractor elected to work at night between the hours of 9 pm to 5 am. The 8-inch pipe and appurtenances have been installed on Ralston Avenue, including 6 service laterals that were switched over. Remaining work on Ralston includes pavement restoration and minor concrete work. Additional piping and appurtenance have been installed on Old County Road from Ralston to approximately 1140 Old County Road (north of Waltermire).

    Contractor submitted twelve (12) extra work requests, and these were evaluated, scope was negotiated, and costs reduced. As of November 30, 2023, Contractor has progressed work ahead of the baseline schedule with approximately 700 feet of new pipe installed. Contractor has 203 of 220 working days remaining.

    Photos of construction crew working on the OCR water main improvement project.
  • CIP Updates - October 2023

    Harbor Boulevard Water Main Improvements

    As of September 30, 2023 C2R Engineering (C2R) successfully finished the installation of all the mains throughout the project and successfully completed one of the tie-ins, allowing them to complete the installation of the fire and water services. Looking ahead to October, C2R will complete the remaining tie-ins, service, and fire connections, as well as complete the final trench paving and the remaining miscellaneous concrete work.

    As of September 30, 2023, the C2R completed 65% of the contractual work and has 60 of 144 working days remaining.

    Photo of work done on MPWD's Harbor Boulevard Water Main Improvement Project
    Photo of work done on MPWD's Harbor Boulevard Water Main Improvement Project
    Photo of work done on MPWD's Harbor Boulevard Water Main Improvement Project
  • CIP Updates – September 2022

    Hastings Drive / Vine Street / Belmont Canyon Road Water Main Improvements

    As of August 31, 2022, C2R completed all project work including final trench paving, slurry seal, and striping. The District deemed the project substantially complete on August 30, 2022 and issued the project punchlist with a desired completion date by September 16, 2022.

    Change Order No. 3 for $7,290.45, includes 5 separate daily extra work report (DEWR) inclusive of several City requested items (additional traffic control plans, work stoppage/delay associated with the concrete valley gutter, and special driveway finishing for the resident at 3204 Upper Lock Ave), Spring Ln service reconnections, and additional striping. This change order also adds 3.5 working days increasing the contract days from 98 to 101.5. Please refer to Change Order No. 3 for additional information.

    Balancing Change Order No. 1 increases the original contract total by $6,915.75 to account for additional materials used during the project. This adjusts the original bid quantities to reflect the actual constructed quantities.

    Image of constructions workers finishing up the Hastings project in August 2022

    Image of constructions workers finishing up the Hastings project in August 2022

    Image of constructions workers finishing up the Hastings project in August 2022

  • CIP Updates – July 2022

    Hastings Drive / Vine Street / Belmont Canyon Road Water Main Improvements

    As of June 30, 2022, C2R completed the remaining tie-in connections, blow offs, and combination air valves along Vine Street in addition to abandoning the Zone 5 to Zone 2 pressure reducing valve vault and portions of the old water main. Vine Street is completely in service with all residents on the new water main. Upon completing Vine Street, C2R transitioned to the Belmont Canyon/Upper Lock area and installed nearly 800 LF of 8" DIP, 11 gate valves, and 11 cathodic protection stations. In July 2022, C2R anticipates finishing the water main installation along Belmont Canyon and Upper Lock inclusive of appurtenances, conducting disinfection/pressure tests, and constructing tie-ins to ultimately transition residents to the new water mains.

    A Change Order in the amount of $38,681.29 includes seven separate daily extra work report (DEWR) requests due to encountering sporadic veins of rock / large boulders in addition to a 6-10" concrete cap over a City owned storm drain within a good portion of the marked alignment along Vine Street. This required alternate equipment to break through the harder material thereby slowing C2R's average production rate. This change order also adds 3 additional working days to the project.

    As of June 30, 2022, C2R completed 80% of the contractual work and has 42 of 98 working days remaining.

  • CIP Updates - June 2022

    Hastings Drive / Vine Street / Belmont Canyon Road Water Main Improvements

    As of May 27, 2022, C2R completed all main line installation along Vine Street (1,445 LF 8" DIP) in addition to all 14 service connections, 3 hydrants, and other miscellaneous appurtenance including cathodic protection items. C2R successfully conducted the 2‐hour pressure test on May 20, 2022 and proceeded to disinfect/flush the water main before beginning the tie‐in connections. On May 27, 2022, C2R made the first of three tie‐in connections along Vine Street beginning at Courtland Road.

    June 2022 work includes the remaining tie‐in connections along Vine Street at Arden and Spring Lanes, installation of the Spring Lane blowoff, and then proceeding to main line installation along Belmont Canyon Road and Upper Lock Avenue.

    During pipe installation along Vine Street, C2R encountered sporadic veins of rock/large boulders and an 8" concrete cap within a good portion of the marked alignment. This required specialized equipment to break through the harder material thereby affecting their production rate. The District is currently negotiating with C2R on their Change Order request.

    As of May 27, 2022, C2R completed 49% of the contractual work, and has 65 of 95 working days remaining.

    Photos of construction work on the Hastings / Vine / Belmont Water Main Improvements Project


  • CIP Updates - May 2022

    Hastings Drive / Vine Street / Belmont Canyon Road Water Main Improvements

    On November 17, 2021, the Mid‐Peninsula Water District (District) awarded C2R Engineering (C2R) the Hastings Drive / Vine Street / Belmont Canyon Road Water Main Improvements. The contract was executed on November 19, 2021. On February 2, 2022 the District held the pre-construction meeting and issued the Notice to Proceed for April 18, 2022 to accommodate material supply chain disruptions/delays. District employee, Victor Fung, was designated as the full‐time, on‐site inspector.

    Work completed during April 2022 included marking the water main alignment, mobilization, potholing, and installation of approximately 600 LF of 8" ductile iron pipe (DIP) and 10 LF of 6" DIP along Vine Street, 1 fire hydrant, and miscellaneous appurtenances.

  • CIP Update – December 2021

    El Camino Real Water Main Project

    Mitchell Engineering has completed installation of 8-inch DIP water main between Ruth Avenue and Middle Road as required by the contract. However, the last segment of the installed pipe, from 530 Block of El Camino Real to Middle Road is yet to pass bacteriological analysis test. Mitchell Engineering is struggling to obtain the required Bac-T results for the segment. As a result, the service laterals within this segment are yet to be connected to the new water main. Also, Mitchell Engineering worked on restoration of the sidewalk and roadway pavements in this estimate period.

    The damaged CCTV conduits and cables at the intersection of El Camino Real and Davey Glen are still not repaired by the contractor. Electrical sub, Bear Electric Solutions has been engaged by Mitchell Engineering to repair the damaged conduits and cables. Based on the most current project schedule, the repair work has been scheduled for December 9, 2021 at nighttime. Caltrans has been notified and would be onsite during the repair work. An extended lane closure request, between the hours of 7:00 pm and 5:00 am has been approved by Caltrans for the repair work. The cost of the repair is $35,350.00. Mitchell Engineering damaged the CCTV cable during trench excavation to install the new 8-inch DIP. MPWD directed Mitchell Engineering to repair the damaged at own cost in accordiance with the project documents. Mitchell Engineering submitted Notice of Potential Claim against the cost of the repairs, and contracted Bear Electric Solutions to perform the repairs.

    To date, about 83% of the contract work items have been completed by the contractor. Contract working days for the project ran out on November 15, 2021. Based on the most recent 3-week look ahead schedule, substantial completion date is December 17, 2021. If this date holds firm, project walk through with Caltrans and City of Belmont Reps will be scheduled for on the week of December 20, 2021. After the walk through, contractor is given a week to address issues or concerns raised during the walk through with Caltrans and City of Belmont. Meanwhile, Liquidated Damages of $1,650.00 per each calendar day of work beyond the contract working days are being charged to Mitchell Engineering in accordiance with the Contract Documents and Construction Specifications.

    Disposal of excavated materials to OX Mountain Landfill continued in November under Contract Change Order #2. As of the cutoff date for this Estimate, about 2,830 tons of excavated materials have been disposed at the landfill. Contract Change Order #2 was written for an estimated 2400 tons of excavated materials, but an overrun of about 300 tons is very likely due to service laterals excavation not included in the original calculations.

    The construction management team along with the contractor continued to notify residents and local businesses along the pipe alignment of work activities that may impact access to their properties during the month. Notification flyers are continuously passed out to the residents. A series of water shutdowns has taken place recently to connect service laterals to the new water main. Residents were given 48 hours shutdown notice as required by the contract documents unless when unforeseen field issues detect otherwise.








  • CIP Update – October 2021

    El Camino Real Water Main Project

    The Contractor has completed installation of the new water main between 564 Block of El Camino Real and Middle Road including fire hydrants and service laterals. Leak test and bacteria test are yet to be performed on this segment. Currently, the Contractor is working on the segment that requires 6-inch temporary water main, between 510 and 530 Blocks of El Camino Real. The Contractor found enough separation between the alignments of the existing 8- inch CIP and the new 8-inch DIP to install the new water main while the existing water main remain in service. Completion of this segment, which includes installation of fire hydrants and service laterals, is projected to October 22, 2021.

    During installation of the new water main between Ruth Avenue and Block 510 of El Camino Real, the Contractor sawcut through existing conduits and signal cables owned by Caltrans at the intersection of Davey Glen and El Camino Real. As a result of this damage, the existing CCTV cables and interconnect cables at the intersection ceased to function. Though, the existing CCTV cables and Signal Interconnect Cables are not shown on the project plans, the contract documents put the responsibility to locate and protect existing facilities on the Contractor. The Contractor is refuting the position of the contract documents but have been directed to repair the damaged cables with their rights for claim reserved to the completion of the project.

    To date, about 65% of the contract work items have been completed, project completion date is projected to November 8, 2021, barring unforeseen circumstances and extensive inclement weather. The construction management team along with the Contractor continued to notify residents and local businesses along the pipe alignment of work activities that may impact access to their properties during the month. Notification flyers are continuously passed out to the residents.

    El Camino Real Water Main Improvement site photo from October 2021

    El Camino Real Water Main Improvement site photo from October 2021

    El Camino Real Water Main Improvement site photo from October 2021

    El Camino Real Water Main Improvement site photo from October 2021

  • CIP Update – August 2021

    El Camino Real Water Main Project

    Contractor continued to install 8-inch water main between 564 Block of El Camino Real and Middle Road, lateral service connections, and fire hydrants along the water main line. Leak test will be performed along these segmented as soon as the installation of the service laterals and fire hydrants are completed and accepted by the District. Temporary 6-inch waterline will be installed after the completed segment are tied into the existing waterline at Ruth Avenue and operational.

    To date, about 55% of the contract work items have been completed, project completion date is estimated to be November 5, 2021, barring unforeseen circumstances and extensive inclement weather. Also, Contractor made a minor change in construction activity sequencing to gain some days from the previous schedules.

    The construction management team along with the Contractor continued to notify residents and local businesses along the pipe alignment of work activities that may impact access to their properties during the month. Notification flyers are continuously passed out to the residents.

    Image of construction work along the El Camino Real in August 2021

    Image of construction work along the El Camino Real in August 2021

  • CIP Update – July 2021

    El Camino Real Water Main Project

    Contractor completed potholing of 8-inch DIP alignment along southbound El-Camino Real, and there was no change to the original alignment set in the construction documents. Installation of 8-inch DIP started at the north end of the project on June 15, 2021 with excavation, placement of bedding, and cement slurry backfill. Excavated soil materials were hauled off the site for disposal at Ox Mountain landfill in Half Moon Bay. The excavated soil materials were classified as a Class 2 waste and attracted a disposal fee of $30.00 per ton at the landfill. A total of 2,000 tons of excavated soil materials is estimated for disposal at the landfill. The disposal fee is an additional cost to the contract, and contract change order has been written to compensate the contractor for the additional cost

    Image of construction work along the El Camino Real

    The construction management team along with the contractor continued to notify residents and local businesses along the pipe alignment of work activities that may impact access to their properties during the month. Notification flyers are continuously passed out to the residents.

    On June 17, 2021 MPWD requested a change order to replace bare copper service laterals with shielded copper along the DIP alignment. District is concerned about the effect of the cement slurry backfill to the bare copper service laterals. Also, the District’s latest Standard Specifications require shielded copper for all service laterals.. The contractor has been directed in writing to furnish and install shielded copper at the service laterals in lieu of the bare copper as provided in the contract documents. A contract change order will be issued to authorize the change and compensate the contractor for any additional costs.

    Image of construction work along the El Camino Real

    Image of construction work along the El Camino Real

    Image of construction work along the El Camino Real

  • CIP Update – June 2021

    El Camino Real Water Main Project

    Mid-Peninsula Water District (MPWD) awarded El-Camino Real Improvements project to Mitchell Engineering on November 24, 2020 following approval by the board and acceptance of the required documentations including bonds and insurance certificates. On January 12, 2021, pre-construction meeting was held, and NTP was issued to the contractor to start work on February 16, 2021.

    Image of construction work along the El Camino Real

    Following the groundbreaking and installations of the project signs, traffic controls signs, and water pollution control BMPs, Mitchell Engineering notified the District in writing of their intention to allocate manpower and equipment to the project in second week of May 2021. The letter cited inadequate manpower to effectively execute the project as the reason for the suspension and stated that the project completion date would remain unchanged. The District accepted the suspension and advised that work activities not requiring a lot of workers such as utility potholing, sampling and testing of soils for PH and resistivity, and classification of the soil for disposal can be performed during the shutdown. May 17, 2021 is the projected return date to field work activities.

    On April 26, 2021, Mitchell Engineering re-mobilized to the jobsite to begin utility potholing; soil sampling and testing for disposal classification. On May 6, 2021, Mitchell Engineering submitted a notice for differing site conditions based on the analytical results obtained from the testing of the soil samples collected over the entire length of the proposed 8-inch DIP. The soil was classified as a Class 2 waste for disposal and would require the material to be disposed of, at a Class II or Class III disposal site. The nearest Class II disposal site to the jobsite is Ox Maintain in Half Moon Bay. The contract documents and construction specifications make it the owner’s responsibility to compensate the contractor for any additional cost due to the differing site conditions. The contractor has submitted a quote from Ox Mountain for the disposal of Class II waste at $30.00 per ton; an estimated 2700 tons of excavated materials will be disposed during trench excavation. MPWD and the contractor have completed negotiating the scope of change and terms of payment and will proceed with preparation and issuance of Change Order #2 letter, to be signed by both MPWD and the Contractor.

    Image of construction work along the El Camino Real

  • CIP Update – May 2020

    2019 Water Main Replacement Project
    Notre Dame Avenue, Cliffside Court, Tahoe Drive Area Water Main Project

    Stoloski & Gonzalez (S&G) completed all water main improvements prior to the March 16th shelter‐in‐place order by the San Mateo County Health Officer. On February 24th, a punch list was issued which included the slurry seal and striping work for the project. With the uncertainty of the pandemic both MPWD and S&G decided that a temporary stop notice should be issued on March 17th. On that date, the project reached the 156th work day with 24 days remaining to reach the 180th contractual days.

    As shelter‐in‐place guidelines began to be defined, the MPWD sent a letter to S&G on April 14th designating the project as an essential infrastructure and the project resumed. The MPWD Inspector and the City of Belmont met on April 21st and finalized the slurry seal and striping limits with the subcontractors. The slurry seal began on April 24th and was completed three days later.

    The striping was completed on May 6th. On May 11th, the MPWD deemed the project substantially complete with less than 10 items remaining on the punch list.

    The full report is available here (PDF)

  • CIP Update – December 2019

    2019 Water Main Replacement Project – Notre Dame Avenue

    Stoloski & Gonzalez (S&G) completed the asphalt concrete (AC) and sidewalk restoration on Notre Dame Avenue in November. S&G has requested a walk through with the City and District to address any concerns before the crew demobilizes to another project.

    Tahoe Drive and Cliffside Court Areas

    As of November 26, S&G completed the last tie‐in connection at the intersection of Tahoe Drive and Muir Way. The water mains and the service connections for this project site are now complete and in operation. On December 2, S&G mobilized to Cliffside Court to pothole for the water main to and get ready to replace the plastic service lines. The Contractor has been granted a few rain days delays due to the weather conditions.

    As of November 27, the last work day of the month, the project reached the 85th day of work out of the 180 contractual working days. There are 95 work days remaining for the project. The project is ahead of schedule.

  • CIP Update – November 2019

    2019 Water Main Replacement Project – Notre Dame Avenue

    During the week of October 7, Stoloski & Gonzalez (S&G) completed the two tie‐in connections on Notre Dame Avenue and Valley View Avenue to complete the integration the of Zone 3 system. On October 24, the Contractor returned to Notre Dame Avenue to remove and abandon existing valves and utility boxes prior to the final asphalt concrete (AC) trench replacement. The grinding subcontractor, ABSL Construction, was on site on October 25 and 28 to grind a 4' wide by 6" deep portion of the trench. The City of Belmont inspector Craig West was on site during the operation and requested to remove and pave roadway sections less than 24" from the gutter pan. Due to the realignment of the water main, there are several sections that were replaced per the City’s request. As of October 31, the paving for Notre Dame Avenue is complete. Minor AC and concrete sidewalk restoration for the water services will be completed at the end of the project.

    Tahoe Drive Area

    On October 10, S&G began work on the Tahoe Drive Area beginning on Tioga Way, then on Muir Way, and finishing on Bryce Court. The Contractor installed a total of 844' of 8" ductile iron pipe (DIP) and three fire hydrant assemblies. The Contractor is working on completing the service laterals before they can pressure test the water mains. A shutdown to tie‐in the water main will be scheduled in the weeks to come in November. As of October 31, the project reached the 67th day of work out of 180 contractual working days. There are 113 work days remaining for the project. The work is progressing on schedule. The homeowner next to the Folger Drive staging area has contacted the District and the City to complain about the dust and the noise in the morning. Both issues have been addressed with the homeowner. S&G is addressing the concerns in a timely matter.


Archived Progress Reports

  • CIP Update – October 2019 +-

    2019 Water Main Replacement Project – Notre Dame Ave.

    During the month of September and early October, Stoloski & Gonzalez (S&G) worked on the Zone 3 water main on Notre Dame Ave. S&G installed 2,074 linear feet of ductile iron pipe (DIP) from Terrace Dr to Valley View Ave. Approximately 75% of the Zone 3 water main was installed shallow and backfilled with control density fill (CDF) due to the existing utilities and road width.

    The new 8” water main was pressure tested successfully on September 12. The water main was disinfected, flushed, and tested for bacteria per the project specifications. Two samples were taken and both results confirmed the absence of bacteria.

    On September 23, S&G tied in the new 8” DIP to the existing Zone 3 water main at the intersection of Notre Dame Ave and Terrace Dr. For the shutdown connection, the District used the closest valve located in front of 1737 Terrace Dr. When the District started to open the valve to introduce water into the system, the stem of valve sheared. Fortunately, the new fire hydrant at Sta. 9+75 on Notre Dame Ave was installed next to the existing hydrant which allowed the District to “jump” or connect the two hydrants together to temporary provide water to more than 30 service connections between 1737 Terrace Ave and Notre Dame Ave. On September 26, the District authorized S&G to repair the valve on Terrace Ave. on time and material (T&M) as part of this project.

    The final Zone 3 connections on Manzanita Ave, and Valley View Ave. were completed on September 20 and October 16 respectively. The Zone 3 Notre Dame Loop Closure is complete and is part of the distribution system eliminating the 2,000 linear feet of dead end main on Terrace Ave. and looping the system. The remaining clean‐up and roadway restoration are scheduled for the week of October 21.

    All Zone 2 service connections have been relocated from the existing 6” cast iron pipe (CIP) to the existing 8” (CIP) on Notre Dame Avenue. Abandonment of the existing 6” CIP water main from Folger Dr. to Middle Road is complete. The Zone 2 connections at Folger Dr, Notre Dame Pl, and Middle Rd completes the Mid‐Notre Dame Abandonment eliminating a 650‐LF of redundant aging 6” CIP water main on Notre Dame Ave.

    Beginning October 10, S&G mobilized on Tioga Way to install the 8” DIP water main. Crew will continue to work through the area to Muir Way and Bryce Ct. As of September 30, the project reached the 46th day of work out of 180 contractual working days. There are 135 work days remaining for the project. Work is progressing with no major customer-related or safety issues.

  • CIP Update – September 2019 +-

    2019 Water Main Replacement Project – Notre Dame Ave.

    On May 23, 2019, the Mid‐Peninsula Water District (MPWD) awarded the construction contract for the Notre Dame Avenue, Cliffside Court, Tahoe Drive Area Water Main Project to Stoloski & Gonzalez, Inc. (S&G). On June 26, the District held a pre‐construction meeting to go over project responsibilities and requirements. The contract was executed on June 27. A Notice to Proceed (NTP) was issued for a start date of July 29. District employee Rick Bisio was designated as the on‐site inspector for this project.

    On July 30, while potholing for an existing water service connection at Station 6+21, S&G encountered the existing 18" storm drain on the same alignment as the proposed water main. The Underground Service Alert (USA) markings of the storm drain was shown at 2' to 3' away from the actual line. The District contacted the City of Belmont to verify their markings using closed circuit television (CCTV) and by August 2, the City accurately marked the storm drain and sanitary sewer from Middle Road to Terrace Road. The new markings representing the actual location of the storm drain and sanitary sewer line curved along the roadway with no intermediate manhole structure. The storm drain and sanitary sewer alignments during the design were based on street markings provided by the City and did not match the lines scoped with CCTV.

    While the contractor performed additional potholing for the gas and water services, two 2" conduits were encountered on the same alignment with 24" of cover. The District contacted the City and verified that it did not belong to the City and could be removed. Fortunately, the conduits were empty.

    Notre Dame Ave is a 19' wide with many utilities including the storm drain, gas main, lateral, sewer and storm drain laterals, three water main lines and services. However due to the complications with the storm drain and sanitary sewer lines, the water main had to be redesigned triggering a change order. The new 8" DIP Zone 3 water main alignment was originally designed to be on the opposite side of the sanitary sewer line to maximize the separation as much as possible.

    The Zone 3 distribution system on Terrace Drive will no longer be a dead‐end and will have a looped system improving the water quality and movement in the distribution system. This project also abandons and reconnects two Zone 2 water mains to one single line.

    The water main installation on Notre Dame Avenue will be completed by the end of September and progressing with no major issues. S&G will soon mobilize to the Tahoe Drive area after Notre Dame Avenue is complete.

    On August 30, the project reached the 25th day of work out of 180 contractual working days. There are 155 work days remaining for the project.

    CIP Update

    CIP Update

    CIP Update

    CIP Update

    CIP Update

    CIP Update

  • CIP Update – July 2019 +-

    Hillcrest PRS Capital Project Complete

    After a successful tie‐in connection and re‐establishing Zone 1 water on May 30th, Stoloski & Gonzalez (S&G) completed the vault’s wall on June 6th. S&G then proceeded with the cover, electrical connections and interior appurtenances with no observed issues to the connection. The District is fine tuning the PRV settings.

    On June 25th, the project was deemed substantial complete. The City of Redwood City, District, and S&G met on July 2nd to go over any correction items. S&G addressed these items and demobilized from the site prior to the expiration of the encroachment permit of July 3rd. The contractor swept the site one last time on July 9th.

    The end of the 45 contractual work days was June 3rd. On May 31st and June 19th, a total of 16 working days were added to the project to account for the rain delays, shutdown rescheduling, and the shipping delays for the additional 20” fittings. The date was revised to June 25th. S&G finished the project within the contractual time for the project. On July 11th the City of Redwood City signed off on the encroachment.

    The homeowners around the project have been very understanding and no issues were reported during construction.

    CIP Update

    CIP Update

    CIP Update

    CIP Update

  • CIP Update – April 2019 +-

    Hillcrest PRS Capital Project Underway

    The Mid-Peninsula Water District Board of Directors awarded a construction contract to Stoloski and Gonzalez in the amount of $649,620 on January 24, 2019 to improve one of the District’s two points of connection to the Regional Water System turnouts located in Redwood City at the Hillcrest Meter Site. This capital project is installing a 20-inch diameter pressure reducing regulator to regulate pressure variances from the Regional Water System and protect the Mid-Peninsula Water District infrastructure from pressure spikes in the Zone 1 distribution system. A notice to proceed was issued for April 1, 2019 with 45 working days scheduled for the project. In anticipation of turning water off from the Regional Water System during a part of the construction, District staff has been flushing the water system in various zones during the day and overnight.

    CIP Update

    CIP Update

    CIP Update

    CIP Update

  • CIP Update – February 2019 +-

    Hillcrest PRS Capital Project Awarded

    During the Mid-Peninsula Water District (MPWD) Board of Directors meeting on January 24, 2019, the MPWD Board awarded the Hillcrest Pressure Reducing Station capital project to Stoloski and Gonzalez. A letter of award (see below) has been sent by the District Engineer to Stoloski and Gonzalez, which gives them 15 days to submit contract documents for review and approval, before a notice to proceed can be issued.

  • CIP Update – July 2018 +-

    2017 Water Main Replacement Project

    During June, Stoloski & Gonzalez (S&G) placed the final permanent paving, slurry sealed and striped. Work during this period also included miscellaneous concrete work and replacement of the fire service connection at Dairy Lane.

    On July 16, 2018, the District deemed the project substantially complete and issued a punchlist with 20 items.

    For more details, download the MPWD 2017 WMR July 2018 Project Update.

    Fire Service Connection (Dairy Lane)
    CIP Update

    Arthur Avenue
    CIP Update

    Folger Drive
    CIP Update

    Karen Road
    CIP Update

  • CIP Update – June 2018 +-

    2017 Water Main Replacement Project

    During May, all tie‐ins along Karen Road were completed and the 8‐inch Fusible PVC water main is fully in service. All service connections were transferred from the old water main to the new water main and all sites were paved and prepped for slurry seal.

    As of June 1, 2018, 8 out of 175 working days remain on the contract (110 contract days with an additional 65 days for Change Orders No.1, thru No.5), with approximately 3% of the work remaining. Remaining work includes slurry seal and striping which will be completed in June. After street restoration, the District will walk the site along with the City of Belmont and S&G to finalize the project punchlist.

    For more details, download the MPWD 2017 WMR June 2018 Project Update.

    Three Valve Set with Temporary Service Connection (Karen Road/O’Neill Ave)
    CIP Update

    T‐Cut/Paving (Arthur Ave)
    CIP Update

    Paving (Karen Road)
    CIP Update

  • CIP Update – May 2018 +-

    2017 Water Main Replacement Project

    During April, all the tie‐ins along Arthur Avenue were completed. The 8‐inch DIP water main is fully in service and all the service connections were transferred from the old pipe to the new 8‐inch water main. In addition, 8‐inch Fusible PVC pipe at Karen Road was fully fused by R&B company and pulled through the existing 12‐inch host pipe by S&G without major incidents.

    As of April 1, 2018, the project has 27 out of 173 working days remaining on the contract (110 contract days with an additional 53 days for Change Orders No.1, thru No.4), with approximately 13% of the work remaining.

    Remaining work on South Road, Folger Road, Folger Court, Mezes Avenue, and Arthur includes slurry seal and striping. Remaining work on Karen Road includes three tie‐ins, service connections, Fire Hydrants, paving, slurry seal, and striping.

    For more details, download the MPWD 2017 WMR May 2018 Project Update.

    Installation of 8” PRV Station (ADLP / Arthur Ave.)CIP Update

    8” PRV Station (ADLP / Arthur Ave.)
    CIP Update

    Tie‐in at Arthur Ave.
    CIP Update

    Fusible PVC operation (Dairy Lane / Karen Road) CIP Update

    Pulling Fusible PVC (Dairy Lane / Karen Road)
    CIP Update

  • CIP Update – April 2018 +-

    2017 Water Main Replacement Project

    During March, with nine rain days, S&G only had a total of 13 working days. During this month 8-inch water main, 8-inch PRV station and all the fire hydrants along Arthur Avenue were installed. Starting in April, S&G will complete the tie-ins along the Arthur Avenue and will move the service meter connections over to the new water main, at the same time an additional crew will install the 8-inch water main along Karen Road.

    On March 08, 2018, S&G requested an additional 35 working days to be added to the contract mainly due to lower production rate caused by unforeseen problems such as utility conflict, changes in water main alignments, etc. The District project team evaluated S&G request and ultimately decided to grant S&G an additional 20 working days.

    As of April 1, 2018, the project has 36 out of 161 working days remaining on the contract (110 contract days with an additional 51 days for Change Orders No.1, No.2, and No.3), with 32% of the work remaining. Remaining work on South Road, Folger Road, Folger Court and Mezes Avenue, includes slurry seal and striping. Remaining work on Arthur Avenue includes three tie-ins, service connections, paving, slurry seal, and striping.

    For more details, download the MPWD 2017 WMR April 2018 Project Update.

    Pipe installation (ADLP/Arthur Ave)
    CIP Update

    Connection to 8” PRV station (ADLP/Arthur Ave)CIP Update

    Pipe installation (Arthur Ave)
    CIP Update

  • CIP Update – March 2018 +-

    2017 Water Main Replacement Project

    During February, water main installation and all the tie‐ins along Mezes Avenue were completed. The new water main is in full service with all service connections transferred. During the last week of February, S&G began construction on Arthur Avenue while a smaller crew wrapped up remaining work on Mezes Avenue.

    During the last week of February, S&G began construction on Arthur Avenue which is anticipated to last three to four weeks subject to weather conditions. As of March 1, 2018, the project has 30 of 132 working days remaining on the contract (110 contract days with an additional 22 days for Change Orders No.1 and No.2), with 50% of the work still remaining. Delays were caused by unforeseen site conditions, water main alignment modifications to avoid existing unknown utilities, and traffic control. Although S&G is using additional crews and staff to make up lost time, they are still behind schedule. S&G is currently working to update the construction schedule however may approach the District in the coming weeks to request additional working days. Meanwhile, they are using larger crews on Arthur Avenue and when they move to Karen Road near the end of March. Remaining work on South Road, Folger Road, Folger Court and Mezes Avenue, includes slurry seal and striping.

    For more details, download the MPWD 2017 WMR March 2018 Project Update.

    Water main installation (Mezes Ave)
    CIP Update

    Hand digging for service connections (Mezes Ave)
    CIP Update

    Tie‐in connection (Mezes Ave/Lyon Ave)CIP Update

    Paving (Mezes Ave.)CIP Update

  • CIP Update – February 2018 +-

    2017 Water Main Replacement Project

    During January, all the tie‐ins along the Folger Drive were completed. New water main along Folger Drive and Folger Court are now fully in service, and all the service connections are transferred. During the last weeks of January S&G start construction on Mezes Avenue, while the additional crew was wrapping up the remaining work on Folger Drive and Folger Court.

    Remaining work on South Road includes slurry seal and roadway striping. Remaining work on Folger Road and Folger Court includes installation of meters’ retaining walls and finishing the road restoration including, trench paving, slurry seal, roadway striping, sidewalks and resident landscaping around the new water meter boxes.

    For more details, download the MPWD 2017 WMR February 2018 Project Update.

    Fire hydrant installation (Folger Drive)
    CIP Update

    Pressure test (Folger Drive/Court)
    CIP Update

    Installation of valve collar (South Road)CIP Update

    New fire hydrant and ARV (Folger Court)
    CIP Update

  • CIP Update – January 2018 +-

    2017 Water Main Replacement Project

    During November, all the tie‐ins along the South Road were completed. The 8‐inch PVC water main is now fully in service and all the service connections are transferred from the 4‐inch to the 8‐inch water main. During December Stoloski & Gonzalez (S&G) moved to Folger Road and was able to install approximately 800 LF of 10‐inch water main along Folger Drive and 100 LF of 8‐inch water main along Folger Court. During the last week of November and again the last two weeks of December, S&G added additional crews, while one crew was wrapping up the remaining work on South Road the main crew was on Folger Drive.

    Remaining work on South Road includes installation of a fire hydrant, air release valve, meters’ retaining walls and finishing the road restoration including, slurry seal, roadway striping, sidewalks and resident landscaping around the new water meter boxes. Remaining work on Folger Road including, tie‐ins, transferring service connection, installation of a fire hydrant, air release valve, finishing the road restoration including, slurry seal, roadway striping, sidewalks and resident landscaping around the new water meter boxes.

    Because of a few rainy days, unforeseen utility crossing, and slower construction progress, S&G is slightly behind schedule. S&G is trying to get back on schedule by adding additional crews.

    For more details, download the MPWD 2017 WMR January 2018 Project Update.

    Pipe installation (Folger Drive & Folger Court)CIP Update

    Abandoned pipe in the trench (Folger Drive)CIP Update

    Three valves set at intersection of Folger Drive and Folger CourtCIP Update

    Rock in the trench (Folger Drive and Folger Court)CIP Update

    Old and new fire hydrants (Folger Drive)
    CIP Update

  • CIP Update – November 2017 +-

    2017 Water Main Replacement Project

    CONSTRUCTION STATUS: On July 27, 2017, the Mid‐Peninsula Water District (MPWD) awarded Stoloski & Gonzalez, Inc. (S&G) the Karen, Mezes, Arthur, South & Folger Water Main Improvements Project. The contract was executed on August 4, 2017 and a pre‐construction meeting was held on August 23, 2017. The District issued the Notice to Proceed for October 2, 2017. District employee Michael Anderson is providing full time, onsite inspection for this project.

    S&G began construction along South Road on October 2, 2017. Work along South Road for October included potholing existing utility locations, installing three 3‐valve assemblies to avoid shutdowns during service meter installations, transferring service connections on the existing 4‐inch CIP water main to the larger 8‐inch PVC main, and installing 1 fire hydrant assembly.

    Change Orders: As of October 31, 2017, no change orders for this project have been processed.

    Project Schedule and Request for Progress Payment No. 1: As of October 31, 2017, S&G completed 7% of the contractual work ($142,200.00). Enclosed please find Progress Payment No. 1 due S&G for this period for $135,090.00 (value of work less 5% retention). The work performed to date has been satisfactory and payment is recommended.

    For more details, download the MPWD 2017 WMR November 2017 Project Update.

    CIP Update

    CIP Update

    CIP Update

    CIP Update

  • CIP Update – October 2017 +-

    CIP Update

    In May 2016, the MPWD Board of Directors approved a capital improvement project list totaling 22 projects throughout the community with a cost estimate exceeding $23 million. These projects had been prioritized mainly due to their history of repairs and pipe age. With the list of projects approved, the Board then focused on how to pay for these needed infrastructure improvements. Following several months of careful deliberation, the Board authorized the issuance of nearly $20 million in “certificates of participation” at historically low interest rates.

    With a list of approved projects and funding in place, MPWD staff secured professional engineering services to augment the District Engineer for the design of several complex capital improvement projects.

    In October 2017, the Water Main Replacement Program began construction. This $2 million program, representing the first five capital projects, will replace water mains in Arthur Avenue, Folger Drive, Karen Road, Mezes Avenue, and abandon an old water line under South Road.

    The following capital projects are currently in the design phase and scheduled to break ground in 2018-2019:

    1. A water pressure reducing station at the Hillcrest Meter Site, a supply point from the SFPUC;
    2. A potential joint project with the City of Belmont for simultaneous water and sewer system improvements on Davey Glenn Road, Francis Avenue/Court and Belburn/Academy Avenue. Redundant and old water mains will be abandoned on Academy Avenue as will a cross country water line east of North Road and north of Davey Glenn Road;
    3. Construction of a new pipeline near the Palo Alto Medical Foundation facility and under State Route 101 and along Shoreway Road;
    4. Consolidation and construction of water lines on Old County Road (OCR) from Bragato Road to Marine View, under the Caltrain along the F Street alignment, on Ralston from OCR to Elmer Street;
    5. Consolidation and construction of water lines on El Camino Real from North Road to Middle, one block in front of Safeway, and a small section near F Street on the south end. System circulation and water pressure improvements will also take place in an area bounded by El Camino Real, North Road, Malcolm Avenue, and Belmont Avenue; and
    6. The 2018 Water Main Replacement Project defined by improvements to Tahoe Drive, the Notre Dame Loop Closure, Cliffside Court improvements, fire hydrant improvements on Desvio Way, Solano Drive, and Altura Way.

    It is anticipated that construction of these projects will take place throughout 2018/2019. More detailed information will be provided by MPWD as these projects get ready for construction.

​Old County Road Improvements

Old County Road Improvements (Projects 15-75, 15-79 and 15-82); CIP #05-1621-CP; currently in engineering design phase; Board awarded design services to Schaaf and Wheeler Consulting Civil Engineers on September 28, 2017.

PROJECT BACKGROUND – OLD COUNTY ROAD

Old County Road spans the entire length of Zone 1 and has approximately 5,000 LF of various 4", 6" and 8" cast iron pipe (CIP) and asbestos cement (AC) water mains installed in the 1930s/1940s located on the east side of the road. In addition, approximately 3,100 LF of 10" and 12" polyvinylchloride (PVC) and polyethylene (PE) water mains in steel casings were installed in the late 1980s and parallel the CIP and AC on the left side of the road. There are approximately 111 service connections, 15 fire service connections, and 11 fire hydrants along the CIP/AC water mains. Hydraulic analysis indicates the larger parallel water mains (10"-12") provide no significant fire flow benefit to the zone. This project abandons 6,475 LF of various sized parallel water main and replaces all of the 6"- 8" CIPIAC with 8" PVC (3,700 LF) and 1,800 LF of 20" CC with 20" PVC from Bragato Road to Marine View Avenue. Distribution System Analysis No. 080.

PROJECT BACKGROUND – F STREET

F Street is located in the southern portion of Zone 1 and crosses El Camino Real where it dead ends before the railroad tracks. A short 150 LF 6" polyvinylchloride (PVC) water main provides service to one business and a hydrant on F Street. Directly to the south of F Street, the District has a 350 LF 10" concrete (CC) water main located in an easement on the CVS property and is 1 of 5 railroad crossings connecting Old County Road with El Camino Real. The 10" CC was installed in 1963 and is currently out of service due to main break with the exact location of the break unknown. This project relocates the existing 10" CC out of the CVS easement to F Street and installs a new 400 LF 8" PVC. The existing 10" CC will be used as a casing for the new 8" PVC underneath the tracks. Hydraulic analysis indicates this particular crossing does not provide significant fire flow benefit however it does provide other benefits including system redundancy and relocation of a water main out of an easement onto public right-of-way. Distribution System Analysis No. 084.

PROJECT BACKGROUND – RALSTON AVENUE

The 500 LF 6" cast iron (CIP) water main along Ralston Avenue between Old County Road and Elmer Street was identified by maintenance personnel as a preferred capital improvement project. The CIP was installed in 1937 and it is probable this water main could experience a significant break in the future. Given the location on the highly traveled Ralston Avenue, a main break would not be ideal and would cause major traffic disruptions. This project replaces the existing 6" CIP with a new 8" polyvinylchloride (PVC) in addition to 5 service replacements and 1 fire hydrant. Traffic control on Ralston Avenue will be challenging where night time work may be a possibility to minimize traffic disruptions.

View PDF »


CIP Map and Project List

Click the map below to zoom and navigate.

CIP Map

Overview

The Mid-Peninsula Water District (MPWD) completed several strategic projects during the past few years, each of them building upon the other, in order to best consider the entire MPWD system and its capital infrastructure rehabilitation and improvement needs, namely:

  • Construction standards and specifications;
  • Water hydraulic modeling and capital program development;
  • Water capacity charges update; and
  • Water financial plan and rate study, including a 2016 update.

First, senior Operations staff, management, and the District Engineer teamed up and revised its construction standards and specifications. These were important not only for consistent construction application throughout the MPWD system for future operations and maintenance, but also in preparation for any major capital improvement program. They are posted at the MPWD website here.

Next, in preparation of a meaningful capital program, the same team systematically reviewed the MPWD’s infrastructure and developed a water hydraulic model to identify deficiencies. This was an 18-month process and one in which institutional knowledge of the MPWD system blended with engineering know-how and management experience resulting in the development of a comprehensive list of needed capital projects within the MPWD system. A distribution system analysis was developed by the District Engineer for each project, including an engineering cost estimate. Nearly 90 capital projects were identified, totaling over $50 million. Operations staff selected several pertinent operational and coordination criteria for evaluating the projects for prioritization. That priority list resulted in the MPWD’s proposed Capital Improvement Program (CIP). A 5-year CIP was developed from this list. The water hydraulic model is a valuable tool for operations and maintenance analyses, development assessments and fire flow reviews, and is maintained to keep it current.

Third, the MPWD hired an independent public finance consultant, Bartle Wells Associates, to work with staff for review and update of the MPWD’s development impact fees and structure. That nearly 9-month process was thoroughly vetted by the Board of Directors to ensure transparent stakeholder and customer participation and input. The result was a Water Capacity Charges Update dated March 20, 2015 and adopted by the Board of Directors per Ordinance No. 112 dated April 23, 2015. Not only were water capacity charges updated for new development requiring a “buy-in” to the MPWD system for its added service impact, but the MPWD also created water demand offset fees to manage the new demand within its available regional water system supply from San Francisco Public Utilities Commission (SFPUC), especially during water shortages. This is in addition to the new development requirements to comply with current building codes requiring high efficient water fixtures. These supplemental revenues depend upon the level of proposed development within the MPWD service area, but are additional resources for capital projects and water conservation/educational programs and public outreach.

Finally, the MPWD updated its water financial plan and reviewed its rates and structure, again with the assistance of Bartle Wells Associates. A rate workshop was held on March 26, 2015. A water financial plan and rate study was presented and adopted by the Board of Directors on May 26, 2015, including phased increases to the monthly fixed system charge and within the tiered structure. Further provisions adopted were pass-through of additional increases by SFPUC to projected wholesale water rates, and emergency water shortage rates should the MPWD experience a significant decrease in its water commodity revenues as a result of greater water use reductions due to a drought.


Water Finance and Rate Update

In FY 2015/2016, water conservation efforts within the MPWD system resulted in lower revenue receipts as well as associated purchased water costs. Therefore, the MPWD contracted with Bartle Wells Associates to update its 2015 finance and rate study in order to adequately prepare for the FY 2016/2017 budget process. The Board received an updated financial report on April 24, 2016. The cash flow projections were decreased as a result of the reduced water consumption, while at the same time considering rate increases effective July 1, 2016. Bartle Wells Associates also took into consideration the potential for a debt financing, and concluded that an annual debt service payment of $1,045,000 could be achieved, even with the reduced cash flow projections. Lastly, excess revenues were forecasted resulting in sufficient coverage required for a debt financing.


5-Year CIP and Financing Options

Since the completion of the above critical projects and since 2015, the MPWD has publicly engaged in discussions around options for implementing a CIP, funding alternatives, and financing details at the following Board meetings:

  • October 11, 2016
  • September 22, 2016
  • August 25, 2016
  • June 23, 2016
  • May 26, 2016
  • April 28, 2016
  • March 24, 2016
  • February 25, 2016
  • January 28, 2016
  • December 16, 2015
  • November 16, 2015

Prioritized projects were presented to and accepted by the Board as a capital program. Staff has been working with its municipal finance advisor, Wulff Hansen & Company, since January 2016, to identify potential options for financing a 5-year CIP. The Board of Directors considered three (3) 5-Year CIP alternatives at its regular meeting on May 26, 2016. They selected Alternative One totaling $20,000,000 and approved Resolution No. 2016-06, which is attached, including the authorized 5-Year CIP.


MPWD Comprehensive System Analysis and CIP FY 2016/2017 Update

As a result of the detailed capital infrastructure modeling and analyses performed, the District Engineer and staff created a report entitled MPWD Comprehensive System Analysis and Capital Improvement Program FY 2016/2017 Update, which was adopted by the Board at its regular meeting on May 26, 2016 (via Resolution No. 2016-06).

During the summer of 2016, the District Engineer and staff developed an added section to the MPWD Comprehensive System Analysis and Capital Improvement Program FY 2016/2017 Update, including their asset management analysis of MPWD water mains and storage tanks and annual pay-go reinvestment requirements. The added section was presented to the Board during its regular meeting on August 25, 2016.


5-Year CIP Detail

Exhibit A of the 5-year Capital Improvement Program FY 2016/2017 through 2020/2021 is available for download (PDF).

View PDF »


2016 COP Project Fund Quarterly Reports

Quarterly reports of 2016 COP project fund expenditures are prepared and presented at regular Board meetings. Available here:

ShowHide All COP Spending Reports +-

July 19, 2023
January 18, 2023
July 22, 2022
January 20, 2022
July 15, 2021
January 22, 2021
July 17, 2020
January 16, 2020
October 18, 2019
June 30, 2019
March 31, 2019
December 31, 2018
September 30, 2018
June 30, 2018
March 31, 2018
December 31, 2017
September 30, 2017
September 30, 2017 – Updated Graph
June 30, 2017
March 31, 2017

ShowHide All COP Spending Report Reconciliations +-

December 31, 2022
June 30, 2022
December 13, 2021
June 30, 2021
December 31, 2020
June 30, 2020
December 31, 2019
September 30, 2019
June 30, 2019
March 31, 2019
December 31, 2018
September 30, 2018
June 30, 2018
March 31, 2018
December 31, 2017
September 30, 2017
June 30, 2017
March 31, 2017

Also available are the 2016 COP Requisitions for Disbursements from Project Fund (see below). These requisitions are formal project fund requests by the MPWD through its COP program Trustee, BNY Mellon. Payments are made directly to the listed payees by BNY Mellon. These expenditures are included in the MPWD 2016 COP Project Fund Quarterly Reports.

ShowHide All Project Fund Requisitions +-

Project Fund Requisition #1
Project Fund Requisition #2
Project Fund Requisition #3
Project Fund Requisition #4
Project Fund Requisition #5
Project Fund Requisition #6
Project Fund Requisition #7
Project Fund Requisition #8
Project Fund Requisition #9
Project Fund Requisition #10
Project Fund Requisition #11
Project Fund Requisition #12
Project Fund Requisition #13
Project Fund Requisition #14
Project Fund Requisition #15
Project Fund Requisition #16
Project Fund Requisition #17
Project Fund Requisition #18
Project Fund Requisition #19
Project Fund Requisition #20
Project Fund Requisition #21
Project Fund Requisition #22
Project Fund Requisition #23
Project Fund Requisition #24
Project Fund Requisition #25
Project Fund Requisition #26
Project Fund Requisition #27
Project Fund Requisition #28
Project Fund Requisition #29
Project Fund Requisition #30
Project Fund Requisition #31
Project Fund Requisition #32
Project Fund Requisition #33
Project Fund Requisition #34
Project Fund Requisition #35
Project Fund Requisition #36
Project Fund Requisition #37
Project Fund Requisition #38
Project Fund Requisition #39
Project Fund Requisition #40
Project Fund Requisition #41
Project Fund Requisition #42
Project Fund Requisition #43
Project Fund Requisition #44
Project Fund Requisition #45
Project Fund Requisition #46
Project Fund Requisition #47
Project Fund Requisition #48
Project Fund Requisition #49
Project Fund Requisition #50
Project Fund Requisition #51
Project Fund Requisition #52
Project Fund Requisition #53
Project Fund Requisition #54
Project Fund Requisition #55
Project Fund Requisition #56
Project Fund Requisition #57
Project Fund Requisition #58
Project Fund Requisition #59
Project Fund Requisition #60
Project Fund Requisition #61
Project Fund Requisition #62
Project Fund Requisition #63
Project Fund Requisition #64
Project Fund Requisition #65
Project Fund Requisition #66
Project Fund Requisition #67
Project Fund Requisition #68
Project Fund Requisition #69
Project Fund Requisition #70
Project Fund Requisition #71
Project Fund Requisition #72
Project Fund Requisition #73
Project Fund Requisition #74
Project Fund Requisition #75
Project Fund Requisition #76
Project Fund Requisition #77
Project Fund Requisition #78
Project Fund Requisition #79
Project Fund Requisition #80
Project Fund Requisition #81
Project Fund Requisition #82
Project Fund Requisition #83
Project Fund Requisition #84
Project Fund Requisition #85
Project Fund Requisition #86
Project Fund Requisition #87
Project Fund Requisition #88
Project Fund Requisition #89
Project Fund Requisition #90
Project Fund Requisition #91
Project Fund Requisition #92
Project Fund Requisition #93
Project Fund Requisition #94
Project Fund Requisition #95
Project Fund Requisition #96
Project Fund Requisition #97
Project Fund Requisition #98
Project Fund Requisition #99
Project Fund Requisition #100
Project Fund Requisition #101
Project Fund Requisition #102
Project Fund Requisition #103
Project Fund Requisition #104
Project Fund Requisition #105
Project Fund Requisition #106
Project Fund Requisition #107
Project Fund Requisition #108
Project Fund Requisition #109
Project Fund Requisition #110


Overview

The Informational Summary of Board Discussions and FAQs (Frequently Asked Questions) for the Proposed Capital Improvement Program (CIP) and Potential Options for Financing is a culmination of Board discussions during late 2015 and throughout 2016 regarding financing options for the MPWD CIP. It can viewed at the link below and includes:

Exhibit A - Resolution No. 2016-16 – Adopting MPWD Comprehensive System Analysis and CIP FY 2016/2017 Update and Authorizing MPWD 5-year Capital Improvement Program for FYs 2016/2017 through 2020/2021 (pp. 9-12);

Exhibit B – FYE June 30, 2015 Capital Assets Graph (pp. 13-14) dated November 18, 2015, and prepared by MPWD Financial Auditor, James Marta & Company, CPAs;

Exhibit C – Sample Private Placement and Public Offerings (pp. 15-21) dated April 27, 2016, prepared by MPWD Municipal Finance Advisor, Wulff, Hansen & Co.; and

Exhibit D – Comparisons – Premium Bonds to Par Value Bonds (pp. 22-28) dated August 24, 2016, and prepared by MPWD Municipal Finance Advisor, Wulff, Hansen & Co.

View PDF


Background

The MPWD’s practice has been to appropriate a certain dollar amount per year, typically between $1 million to $1.5 million dollars, to fund capital projects on a cash “pay go” basis. There is no systematic way of evaluating if this level of funding was adequate to ensure the timely replacement of MPWD infrastructure.

The pay-go system has allowed the MPWD to slowly replace some deficient distribution pipeline segments and rehabilitate or replace some tanks that were not seismically safe. But much of the MPWD water system is more than 50 years old and is spread out over nine (9) distinct pressure zones. The system’s age in combination with system pressures exceeding 120 pounds per square inch (psi), have led to and continue to create many water leaks, which has wasted millions of gallons of water and resulted in personnel and maintenance costs to repair main breaks.

The comprehensive analysis resulting from the water hydraulic modeling indicates the MPWD has historically been underfunding its capital infrastructure needs and now must undertake an accelerated program to catch up. If it does not, the MPWD system risks falling further behind and being vulnerable to severe damage during a large seismic event and increased maintenance costs.

The external financial auditor, James Marta & Company, reported on November 18, 2015, that the MPWD’s existing capital replacement is not keeping pace with the annualized depreciation of the system, thereby an increased level of capital spending was recommended.

Auditor Graph


Financing and Funding Options

  • Continue on a “pay-go” basis. Utilize available revenues to pay for planned projects. It will take 16 years to pay for $25 million planned 5-year CIP. Cost of unexpected maintenance will reduce available funds and extend over 16 years’ completion of planned projects. Current ratepayers pay for capital projects while future ratepayers do not pay an equitable share. The MPWD may experience an impairment of its operations due to delayed needed infrastructure improvements.
  • Debt. Ability to finance much needed capital improvements now. Rates are the lowest in 25 years. Term of debt can be flexible from 10 to 30 years. The debt can be structured to allow pre-payment after 10 years.
  • A hybrid approach, including a combination of debt and “pay go.” Debt will be issued to complete capital projects and use all excess revenues that can be used for “pay go” or pay down the debt, which shortens the term of the debt.
  • Returning to only “pay go” depends upon how much of the excess revenues after debt service is applied to early payment of the debt. First additional reduction of the debt beyond the scheduled payment of principal will occur after 10 years.

Four (4) cash sources were identified for CIP funding on a continued “pay-go” basis, or for annual loan/debt service payments, or a combination of both: Water revenues, development impact revenues, reserves, or real property sales. The Board of Directors would authorize the funding source(s) for any approved CIP.

  • Water revenues can be used for any type of improvement related to the MPWD’s business.
  • Development impact revenues are normally used and may have statutory requirements such that they can only be used to support the construction of new infrastructure and facilities to support the impacts of growth to the system.
  • Reserves, unless restricted, are an available cash source that could be used as a funding source;
  • Real property sales proceeds, generally speaking, and unless restricted, could be used as a source of funding.

Standard and Poor's "AA" Rating for the MPWD

S&P “AA” Rating Letter (November 15, 2016)
S&P “AA” Rating Report (November 15, 2016)


Debt Financing Consideration and Approval

On October11, 2016, a Special Board Meeting was held to consider Resolution 2016-20 approving the form and authorizing and directing the execution of certain installment sale financing documents in connection with the financing of the acquisition and construction of certain improvements and facilities within the District’s water system, authorizing and directing distribution of a Notice of Intention, a Notice of Sale and a Preliminary Official Statement in connection with the related offering and sale of Certificates of Participation (the “COPs”), and directing certain related actions. After presentations by staff and MPWD Municipal Finance Advisor, Bud Levine of Wulff, Hansen & Co., and discussions about the proposed debt sale, the Board approved Resolution No. 2016-20. The staff report and related attachments are included here:

Agenda Item 3.A (October 11, 2016)
Resolution No. 2016-20 Approved (October 11, 2016)
Public Offering – 30-Year Premium (October 7, 2016)
Capital Assets (May 2016)
Premium Pay Go (October 7, 2016)
MPWD Comps (September 2016)
Notice of Intention to Sell Securities (September 13, 2016)
Official Notice of Sale (September 13, 2016)
Installment Sale Agreement (September 13, 2016)
Trust Agreement (September 13, 2016)
Continuing Disclosure Certificate (September 13, 2016)
Certificates of Participation - Preliminary Official Statement (October 31, 2016)


Final Official Statement

Download here (PDF)


MPWD COP Sale on December 7, 2016

Ben“Bud” Levine and Edmund Viray of Wulff, Hansen & Company presented an overview of the $18,750,000 COP (Certificates of Participation) sale on December 7, 2016 for the MPWD’s CIP financing.

It was a competitive bidding process and there were seven (7) bidders that submitted proposals. Citigroup Group Markets, Inc., proposed the lowest TIC (True Interest Cost) and most responsive bid. The bid results were as follows:

Competitive Bids


MPWD 2016 COP Financing Documents

A 01. List of Financing Participants
A 02. Public PF Corporation of California Resolution No. 2016-36
A 03. Mid-Peninsula Water District Resolution No. 2016-20
A 04. Acknowledgment of Receipt of Report of Proposed Debt Issuance
A 05. Affidavit of Publication of Notice of Intention to Sell Securities
A 06. Preliminary Official Statement
A 07. Official Notice of Sale
A 08. Certificate of Award to Citigroup Global Markets Inc.
A 09. Good Faith Deposit Custody Agreement
A 10. Installment Sale Agreement
A 11. Assignment Agreement
A 12. Trust Agreement
A 13. Continuing Disclosure Certificate of the District
A 14. Final Official Statement
A 15. Certificate of Delivery of Report of Final Sale to CDIAC
B 01. Incumbency and Signature Certificate of District
B 02. Certificate as to Arbitrage and Tax Compliance Procedures
B 03. Certificate of District
B 04. Rule 15c2-12 Certificate
B 05. Certificate Regarding Use of Proceeds
B 06. Requisition for Disbursement from Project Fund
B 07. Requisition No. 1 for Disbursement from Delivery Costs Fund
B 08. Written Order to Trustee Regarding Investments
B 09. Certificates of Insurance
B 10. Certificate of Mailing Information Return
B 11. Opinion of Hansen Bridgett LLP
B 12. Letter of Quint & Thimmig LLP
C 01. Certificate of Status - Domestic Corporation (California)
C 02. Certificate Regarding Effectiveness of Articles of Incorporation
C 03. Incumbency and Signature Certificate of the Corporation
C 04. Certificate of the Corporation
C 05. Written Request of the Corporation to the Trustee
D 01. Authentication and Incumbency Certificate of the Trustee
D 02. Certificate of Trustee
D 03. Trustee's Receipt of Proceeds
D 04. Opinion of Counsel to the Trustee
E 01. Rating letter of S&P Global Ratings
E 02. Certificate of Underwriter
E 03. Receipt of Certificates of Participation
E 04. Specimen Certificates of Participation
F 01. Final Approving Legal Opinion of Quint & Thimmig LLP
F 02. Reliance Letter to Underwriter
F 03. Reliance Letter to Trustee
G 01. Final Numbers


Costs of 2016 COP Sale

The par amount of the COPs sold on December 21, 2016, was $18,570,000 for the MPWD’s CIP (Capital Improvement Program). A premium of $938,447.30 was added to bring the total sale proceeds to $19,508,447.30. Underwriters fees were $114,426.48, resulting in net proceeds totaling $19,143,020.82, as reflected in the Sale and Delivery of Certificates chart below from the first quarterly report delivered to the Board of Directors on April 27, 2017.

Issuance costs paid totaled $208,124.50 (itemized in the Cost of Issuance chart below) were less than the estimated $251,000.00, and resulted in $42,875.50 being transferred to the 2016 COP Project Fund. The related requisition forms for the issuance costs paid by the MPWD trustee, BNY Mellon, from the 2016 COP Delivery Costs Fund are attached here:

Requisition #1
Requisition #2


Continuing Disclosure Reports

The MPWD is required to file annual Continuing Disclosure Reports associated with the 2016 COP debt financing for its CIP, and it contracted with Dan Bergmann of IGServices to provide those services. The letter agreement for Mr. Bergmann’s professional services can be found here. The MPWD’s Annual Continuing Disclosure Reports are publicly presented and available below.

2016 COP Disclosure Report
2017 COP Disclosure Report
2018 COP Disclosure Report
2019 COP Disclosure Report
2020 COP Disclosure Report
2021 COP Disclosure Report


Municipal Finance Advisor

The MPWD contracted with Wulff, Hansen & Co., a local Municipal Finance Advisor, to assist the MPWD during the 2016 COP sale and issuance process, including financial advice, Trustee selection, and contracting with a Dissemination Agent for the annual Continuing Disclosure reporting. Ben “Bud” Levine is the principal contact at Wulff, Hansen & Co. The MPWD’s contract documents with Wulff, Hansen & Co. are located here:

Wulff Hansen MFA Agreement Addendum, July 13, 2020
Wulff Hansen MFA Agreement, November 3, 2017
Wulff Hansen MFA Agreement Addendum, November 3, 2017
Wulff Hansen MSRB Rule G-42, June 2016

2019 Water Main Replacement Project

Notre Dame Ave. Loop Closure (Project 15-10); Mid-Notre Dame Ave. Abandonment (Project 15-49); Tahoe Dr. Area Improvements (Project 15-28); Cliffside Court Improvements (Project 15-38); Zone 5 Fire Hydrant Upgrades (project 15-06).

PROJECT BACKGROUND – NOTRE DAME AVENUE LOOP CLOSURE

According to the District GIS map and discussions with District personnel, water mains along Arbor Avenue and a small portion on Notre Dame Avenue were abandoned. As a result, this created a long 2,100 LF dead end on Terrace Drive and the District has reported water quality issues near the end of the dead end main. In addition, several water mains along Notre Dame Avenue (between Valley View Avenue and Manzanita Avenue) and the Terrace Drive dead end are incapable of meeting the minimum recommended fire flow of 1,500 gpm at 20 psi. This improvement will reconnect Terrace Drive with Notre Dame Avenue at Manzanita Avenue with 1,030 LF of new 8" ductile iron pipe (DIP) thereby eliminating the dead end. In addition, 1,200 LF of new 8" DIP will replace aging, undersized 4" and 6" water mains along Notre Dame Avenue. Three fire hydrants and 29 service connections will also be replaced. Hydraulic analysis indicates a 12% to 106% increase in available fire flows along Terrace Avenue and Notre Dame Avenue upon completion of this project. Distribution System Analysis No. 013.

PROJECT BACKGROUND – MID-NOTRE DAME AVENUE ABANDONMENT

Notre Dame Avenue between Folger Drive and South Road has two parallel Zone 2 water mains: an 8" cast iron (CIP) installed in 1951 and a 6" CIP installed in 1935. Fire flows under existing conditions are very strong in the area with flows well above the minimum recommendation of 1,500 gpm at 20 psi. This project abandons the existing 6" CIP and reconnects all branch connections and service connections to the existing 8" CIP. Hydraulic analysis indicates there is no adverse affect in abandoning the 6" CIP and fire flows remain nearly identical. Although the existing 8" CIP is also an aging water main, potential replacement of this water main will be on another distribution analysis involving all of the 8" water main on Notre Dame Avenue from Folger Drive to Hersom Tank. Distribution System Analysis No. 053.

PROJECT BACKGROUND – TAHOE DRIVE AREA IMPROVEMENTS

Water is currently provided to Tioga Way, Bryce Court and Muir Way through 300 LF, 400 LF and 200 LF 4" cast iron pipes (CIP) respectively, installed in the late 1950s. Fire flows along each of these streets are below the recommended minimum of 1,500 gpm at 20 psi. In addition, Tioga Way and Bryce Court have dead ends with blowoffs. This project replaces the aging and undersized water mains with new 8" ductile iron pipe (DIP). Two hydrants and 28 service connections will be replaced in conjunction with replacing the blowoffs with new hydrants. An analysis on water age indicates minimal effects with the increase in pipe size. Hydraulic analysis indicates as much as a 130% increase in available fire flows upon completion of this project. Combining this project with the West Belmont Tank Water Main Improvements Project increases fire flows as much as 238%. Distribution System Analysis No. 030.

PROJECT BACKGROUND – CLIFFSIDE COURT IMPROVEMENTS

Water is currently provided to 14 residences on Cliffside Court through 330 LF 4" polyvinylchloride pipe (PVC) originally installed in 1976. The existing available fire flows (588 gpm) on Cliffside Court are significantly below the recommended 1,500 gpm at 20 psi residual. This project replaces the existing 4" PVC with new 8" ductile iron pipe (DIP), replaces the existing fire hydrants, and replaces all 14 services. Hydraulic analysis indicates a 300% increase in available fire flow to 2,350 gpm to Cliffside Court upon completion of this project. An analysis on water age indicates minimal effects with the increase in pipe size. Distribution System Analysis No. 040.

PROJECT BACKGROUND – ZONE 5 FIRE HYDRANT UPGRADES

Desvio Way, Solana Drive and Altura Way are each located in Zone 5 and each has one hydrant located along their midpoints. Desvio Way and Solana Drive are dead end streets with no fire hydrants at their ends and hydrant spacing along all the streets is not optimal. This project improves the hydrant spacing and provides flushing capabilities at the dead ends by installing 4 new fire hydrants. The existing 3 fire hydrants would also be replaced as part of this project to bring them up to current standards. There will also be an added benefit in increasing fire flow protection to residents in Zone 5.

View PDF »


Hillcrest Pressure Regulating Station

Hillcrest Pressure Regulating Station (Project 15-87); CIP # 02-1621-CP; currently in engineering design phase; Board awarded design services to Pakpour Consulting Group (District Engineer) on February 23, 2017.

PROJECT BACKGROUND

The District's water Is supplied from the SFPUC at two main Inlets: the Tunnels Pump Station, located on Canada Road near the Crystal Springs Reservoir, and Hillcrest Meters, located In Redwood City. The Tunnels Pump Station sends water Into Zone 8 (the highest zone In the District) and the Hillcrest Meters sends water Into Zone 1 (the lowest zone In the District). The Hillcrest Meters connection Is a simple connection with a flow meter and has no pressure regulating capabilities. The District has reported multiple pressure fluctuations In Zone 1 due to SFPUC oscillating pressures upstream of the meter. Because of the incapability of regulating pressures downstream of the SFPUC connection, the District has run Into operational Issues. This project Installs a pressure regulating station consisting of multiple pressure reducing valves (PRV) to operate under specific Zone 1 operating conditions. A new vault wlll be constructed downstream of the HIiicrest Meters and will house up to 3 PRVs, two 6" and one 8". Each PRV wlll operate under conditions such as low flows, high demands, and under Hannibal Pump Station operation.

Hillcrest Pressure Regulating Station

Hillcrest Pressure Regulating Station

View PDF »


Karen, Mezes, Folger, Arthur, and South Water Main Improvements

Karen, Mezes, Folger, Arthur, and South Water Main Improvements

These projects, which were combined into one project for construction cost savings, are identified among the highest priority projects within the Mid-Peninsula Water District’s (MPWD) Capital Improvement Program developed in 2015 after extensive water hydraulic modeling of the entire MPWD system. MPWD’s total estimated cost for all five projects is $2.5 million, including engineering design, project management, and construction. It will be funded with proceeds from a 2016 long-term debt financing.

The MPWD cordially invites you to an open house it is hosting regarding these projects on Wednesday, July 19, 2017, from 5:00 pm to 6:30 pm, at the MPWD headquarters at 3 Dairy Lane in Belmont. Please come and learn more about the projects and interact with the project team.

PROJECT PROGRESS REPORTS

MPWD 2017 WMR Project Update (November 6, 2017)

Karen, Mezes, Folger, Arthur, and South Water Main Improvements

View PDF »


​Joint Water/Sewer Project with City of Belmont

Joint Water/Sewer Project with City of Belmont (Projects 15-43, 15-51 and 15-53); CIP #03-1621-CP; design completed; project bid opening January 10, 2018; City of Belmont Public Works is the lead agency; District inspecting their water improvements and paying their fair share of construction related costs; don’t have construction start date but anticipate it will be within next 30-60 days; Board awarded design services to Schaaf and Wheeler Consulting Civil Engineers on January 26, 2017.
Agreement Regarding Joint Sewer Rehabilitation and Water Main Replacement Project

PROJECT BACKGROUND – NORTH ROAD CROSS COUNTRY / DAVEY GLEN ROAD

The water mains along Davey Glen Road were Installed in 1961 and comprise of 600 LF of 6" cast iron pipe (CIP) and 800 LF of 8" CIP. Water is supplied to Davey Glen from Middle Road and a 6" CIP cross country (CC) water main, installed in 1962, extending down from North Road to where the 6" CIP on Davey Glen transitions to the 8" CIP. The CC water main runs beneath a 4 ft wide sidewalk along a dedicated easement. This project abandons the CC water main and replaces 1,400 LF of CIP water main along Davey Glen Road with 8" DIP to correct fire flow deficiencies upon the CC abandonment.

PROJECT BACKGROUND – FRANCIS AVENUE / COURT

Francis Avenue is located between Fairway Drive and Notre Dame Avenue and has a 640 LF 4" polyvinylchloride (PVC) water main installed in 1975. Francis Court is located directly off Francis Avenue and also has 190 LF of 4" PVC installed in 1976. This project replaces a total 830 LF of 4" PVC with 8" ductile iron pipe (DIP) and adds an additional hydrant in the area.

PROJECT BACKGROUND – ACADEMY AVENUE / BELBURN DRIVE

Academy Avenue between Ralston Avenue and Belburn Drive has two parallel water mains: a 600 LF 4" polyvinylchloride (PVC} water main installed in 1970 and a 6" cast iron (GIP} water main installed in 1977. Hydraulic analysis indicates the existing 4" PVC provides little hydraulic benefit to the system. It is assumed the existing services are located on the 4" PVC. In addition, Belburn Drive between Academy Avenue and Villa Avenue also has a 300 LF 4" PVC water main incapable of achieving the minimum recommended fire flow. The two 4" PVC water mains aforementioned connect to each other at Academy Avenue. This project abandons the existing 4" PVC on Academy Avenue, relocates 22 service connections to the existing 6" GIP, and replaces 150 LF of PVC on Belburn Drive with 8" ductile iron pipe (DIP) connecting it to the existing 6" GIP on Academy Avenue.

View PDF »


​State Route 101 Crossing at PAMF Hospital

State Route 101 Crossing at PAMF (Project 15-72); CIP #04-1621-CP; currently in engineering design phase; Board awarded design services to West Yost Associates on May 25, 2017.

PROJECT BACKGROUND

Two State Route 101 (SR 101) water main crossings exist in Zone 1 including a 500 LF 12" asbestos cement (AC) crossing between Karen Road and Sem Lane and another 12" polyvinylchloride (PVC) crossing a half mile to the north. The 12" AC was installed in 1963 in a 36" steel casing. As part of the PAMF development agreement at the south end of Zone 1, the District obtained a 15 ft easement along the northeast side of the PAMF property In addition to a 40 ft x 40 ft area In the northeast corner to serve as a staging area for an alternate SR 101 crossing. This project abandons the aging 12" AC crossing and relocates it to the PAMF easement with a new 1,100 LF 12" PVC water main. To loop the water main back to the existing water main on Shoreway Road requires the installation of an additional 1,200 LF 8" PVC. Hydraulic analysis indicates increased fire flows along Shoreway Road of approximately 200 gpm. This project will require extensive Caltrans coordination. Distribution System Analysis No. 077.

View PDF »


​El Camino Real Improvements

El Camino Real Improvements (Projects 15-74 and 15-76); CIP #06-1621-CP; currently in engineering design phase; Board awarded design services to Hydroscience Engineers, Inc on May 25, 2017.

PROJECT BACKGROUND – EL CAMINO REAL

El Camino Real is located in the western portion of Zone 1 and spans the entire length of the Zone for approximately 8,400 LF. The exisling water mains along the road consist of 100 LF of 8" asbestos cement (AC), 1,700 LF of 8" ductile iron pipe (DIP), 3,800 LF of cast iron pipe (CIP), and 1,300 LF of polyvinylchloride (PVC) for a total 6,900 LF as shown. The District has reported several leaks along the alignment primarily along the CIPs which where installed in 1950 compared to all other pipe on the road installed in the 1990s. This project replaces the 3,800 LF of 8" GIP with 8" DIP, in addition to the lnstallation of 300 LF of new 8" DIP. There are also 8 fire hydrants, 4 fire services, and 23 service connections that will be replaced. Hydraulic analysis indicates an 8" water main along El Camino Real is sufficient to provide fire flows well above the minimum 1,500 gpm at 20 psi. Distribution System Analysis No. 081

PROJECT BACKGROUND – MALCOLM AVENUE

The neighborhood along Malcolm Avenue, Anita Avenue, Julia Court, and Belmont Avenue is currently served by Zone 2 and consists of 55 residences and 5 fire hydrants. Streets to the immediate north of Malcolm Avenue and those on Ruth Avenue and North Road are all served by Zone 1. The zones are connected at the North Road Regulating Station in addition to four other connections via closed valves creating 5 dead ends within the area. This project eliminates all the dead ends except the one associated with the North Road Regulator by installing a new parallel 550 LF ductile iron pipe (DIP) water main along the existing Zone 2 water main on Malcolm Avenue. The existing Zone 2 water main would become part of Zone 1 and the new water main would become part of Zone 2. Hydraulic analysis Indicates a static pressure loss of approximately 40 psi to an average 98 psi with the Zone 2 to Zone 1 switch. Fire flows are minimally affected with differences around 100 gpm on average however the majority of the nows are above 2,000 gpm. Distribution System Analysis No. 079.

View PDF »


Alameda de las Pulgas Water Main Replacement

Alameda de las Pulgas Water Main Replacement

The existing 6 inch and 8 inch cast iron pipe (CIP) water mains along Alameda de las Pulgas between Cipriani Boulevard and Arbor Avenue were installed in the mid-1950s and have experienced numerous water main breaks over the past several years. The Mid-Peninsula Water District (MPWD) replaced a 320 LF section from Belle Monti Avenue to Coronet Boulevard in recent years. The upcoming project will replace the remaining sections of water main between Cipriani Boulevard and Arbor Avenue with new 8 inch ductile iron pipe (DIP), eliminating the 6 inch and 8 inch aged pipe along this road.

This project is identified among the highest priority projects within the MPWD’s Capital Improvement Program developed in 2015 after extensive water hydraulic modeling of the entire MPWD system.

Alameda de las Pulgas Water Main Replacement

View PDF »


Alameda de las Pulgas Water Main Replacement Detour Maps

Click on the link to view the road closure detour maps.

View PDF »


Buckland Tank Project

Fall 2014 Update

Time lapse video of the Mid-Peninsula Water District (MPWD) Buckland Water North Tank replacement project, from start to finish.


Spring 2014 Update

Buckland water tank replacementPlans to replace two water storage tanks on Buckland Avenue in San Carlos are 100% complete. Local utilities relocated a utility pole and power lines away from the tank site. The MPWD project team met with neighbors in the area to obtain input on the project. Construction is due to start mid-March, and will take approximately six months to finish. When complete, residents will have two seismically resistant tanks to provide drinking water and fire protection. The more than 50-year-old tanks were not earthquake resistant and potentially could leave customers in the area without water service or fire protection following an earthquake.

Spring 2013 Update

For more than a year, MPWD has been working with its engineering firm, Pakpour Consulting Group, Inc., to remove and replace two water tanks in the Buckland Avenue area. These tanks provide the only water storage in that area. The project design is now 60% complete with a target completion date of late 2014. The two 100,000-gallon tanks are more than 50 years old, seismically unstable, and beyond repair. The project requires demolishing and hauling off the old tanks and constructing and installing the new ones. It also includes building new foundations, a retaining wall, fencing and piping. The replacement must be done in two phases, as one tank has to stay in operation at all times. According to General Manager Tammy Rudock, “The project is very challenging because the location is extremely tight and MPWD shares the driveway with two neighbors who are less than 50 feet from the tank site. Our engineering staff has had ongoing meetings with the neighbors in the area, and we will continue to keep them informed during the entire process.”

(PDF not available)


Long-Term CIP Project List

The following is a zone by zone breakdown of identified projects, according to the Comprehensive System Analysis and Capital Improvement Program FY 2016 – 2017 Update. Those projects generated as a result of a DSA report are identified accordingly.

Zone 1

(18 Projects)

15‐68 ‐ Wessex Way Dead End Improvements – Replaces 220 LF of a dead end 4” PVC with 8” PVC to replace aging / undersized infrastructure and improve fire flows.

15‐69 ‐ Sussex Court Improvements – Replaces 130 LF of a dead end 4” PVC with 8” PVC in addition to a new fire hydrant to replace aging / undersized infrastructure and improve fire flows.

15‐70 ‐ Shoreway Road Improvements – Abandons 850 LF of 8” AC paralleling a 12” PVC to eliminate aging infrastructure and reduce maintenance.

15‐71 ‐ Wessex Way Loop Improvements – Eliminates an 825 LF 6” PVC dead end by installing 230 LF of 8” PVC to loop the water main within the Sterling Place Development, provides system redundancy, improves fire flows, and improves water quality.

15‐72 ‐ SR 101 Crossing at PAMF Hospital – Abandons 500 LF of 12” AC under SR 101 in favor of a new 12” PVC crossing at the PAMF location eliminating aging infrastructure, dead ends, creates a looped system, and constructs a serviceable underground inter‐tie utility vault. *COMPLETED*

15‐73 – Karen Road Improvements – Replaces 800 LF of parallel 12” AC and 8” CIP with a single 8” PVC to replace aging infrastructure and minimize maintenance. *COMPLETED*

15‐74 ‐ Malcolm Avenue Improvements – Installs 550 LF of 8” DIP to allow a Zone 1 and Zone 2 boundary reconfiguration improving static pressures, eliminating 4 dead ends, and creating looped systems in both Zones.

15‐75 ‐ Old County Road Improvements – Abandons 6,475 LF of parallel water mains and installs 3,700 LF of 8” PVC to replace aging infrastructure, reduce maintenance, and improve fire flows.

15‐76 ‐ El Camino Real Improvements – Replaces 4,100 LF of 8” CIP with 8” DIP to replace aging infrastructure, reduce maintenance, and improve fire flows. *COMPLETED*

15‐77 ‐ Sixth Avenue (Zone 1) Improvements – Installs 200 LF of 8” DIP and a 6” PRV to eliminate 4 dead ends, provide Zone 1 redundancy with a Zone 2 connection, and to improve water movement.

15‐78 – Civic Lane Improvements – Replaces 1,800 LF of various sized water main with new 8” DIP to replace aging infrastructure, shorten a dead end, loop the water main, and improve fire flows.

15‐79 – F Street Improvements – Installs 400 LF of new 8” DIP to replace an out‐of‐service 10” CC with an unknown break location, relocates District facilities out of private property, increase system redundancy.

15‐80 – Bragato Road Improvements – A replacement / new installation combination of 1,000 LF of 8” PVC to replace aging infrastructure, shorten a dead end, loop the water main, and improve fire flows.

15‐81 ‐ Sixth / O’Neill Avenue Improvements – Abandons 1,400 LF of 4”‐8” CIP/PVC and replaces 1,500 LF of 18” CC with DIP to eliminate parallel water mains, reduce maintenance, and improve fire flows.

15‐82 ‐ Ralston Avenue Improvements – Replaces 500 LF of 6” CIP with 8” PVC to replace aging infrastructure.

15‐84 – Ralston Avenue Regulator Relocation – Relocates the regulating station to a more accessible location.

15‐85 – O’Neill Slough Bridge Crossing Assessments – Assesses existing water main conditions, their associated suspension systems, and seismic resistance.

15‐87 – Hillcrest Pressure Regulating Station – Installs a pressure regulating station off the District’s Zone 1 connection to SFPUC to eliminate Zone 1 pressure fluctuations.

Zone 2

(27 Projects)

15‐41 ‐ Mills Avenue Improvements – Replaces 280 LF of 4” CIP with 8” DIP and adds an additional fire hydrant to replace aging / undersized infrastructure and improve fire flows.

15‐42 ‐ North Road Improvements – Abandons 500 LF of 8” CIP paralleling an 8” PVC and relocates services to the 8” PVC to eliminate aging infrastructure and reduce maintenance.

15‐43 ‐ North Road Cross Country / Davey Glen Road Improvements – Abandons 400 LF of cross country 6” CIP and replaces 1,400 LF of 6”‐8” CIP with 8” DIP to eliminate the cross country water main, reduce district maintenance, and replace aging infrastructure.

15‐44 ‐ South Road Abandonment – Abandons 1,325 LF of 4” CIP paralleling an 8” PVC and reconnects the branches to the 8” PVC to reduce maintenance, eliminate aging infrastructure and improve fire flows.

15‐45 – Hainline Drive and Vicinity Improvements – Abandons 400 LF of cross country 4” CIP, replaces 1,740 LF of 4” CIP with 8” DIP along with additional hydrants to eliminate a cross country water main and to improve fire flows.

15‐46 – Miramar Terrace Improvements – Replaces 1,250 LF of 4” CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐47 – Virginia Avenue Improvements – Abandons 210 LF of cross country 6” CIP/PVC and replaces 950 LF of 6” CIP with 8” DIP to abandon an inaccessible cross country water main, replace aging infrastructure, and improve fire flows.

15‐48 – Willow Lane Improvements – Abandons 230 LF of cross country 4” CIP in favor of a new 600 LF 8” DIP located within the roadway and adds a fire hydrant to eliminate a cross country water main and improve fire flows.

15‐49 – Mid‐Notre Dame Avenue Improvements – Abandons 650 LF of 6” CIP paralleling an 8” CIP to remove aging infrastructure and reduce maintenance.

15‐50 – Fairway Drive Improvements – Replaces 1,420 LF of 4” PVC with 8” DIP and adds an additional fire hydrant to eliminate undersized insfrastructure and improve fire flows.

15‐51 – Francis Avenue / Court Improvements – Replaces 830 LF of 4” PVC with 8” DIP and adds an additional fire hydrant to eliminate undersized infrastructure and improve fire flows.

15‐52 – Chevy / Clee Streets Improvements – Replaces 780 LF of 4” PVC with 8” DIP and adds an additional fire hydrant to eliminate undersized infrastructure and improve fire flows.

15‐53 – Academy Avenue / Belburn Drive Improvements – Abandons 600 LF of 4” PVC paralleling a 6” CIP and replaces 300 LF of 4” PVC with 8” DIP to eliminate undersized infrastructure and improve fire flows.

15‐54 – Villa Avenue Improvements – Replaces 1,500 LF of 4” PVC / 6”CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows. This project also reconfigures water services connections so each resident has their own dedicated service line.

15‐55 – Covington Road Improvements – Replaces 1,000 LF of 4” CIP / 6”DIP with 8” DIP and adds an additional fire hydrant to replace aging / undersized infrastructure and improve fire flows.

15‐56 – Carlmont Drive Improvements – Abandons 800 LF of 8” CIP paralleling a 10” PVC to reduce maintenance.

15‐57 – Alomar Way Improvements – Replaces 750 LF of 4” CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐58 – Fernwood Way Improvements – Replaces 800 LF of 4” CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐59 – Valdez Avenue Improvements – Replaces 1,000 LF of 4” CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐60 – Escondido Way Cross Country Abandonment – Abandons 300 LF of 4” CIP located between two homes to eliminate aging / undersized infrastructure.

15‐61 – Chula Vista Drive Improvements – Replaces parallel 6” / 8” CIP with a single 10” DIP to complete a uniform 10” water main between Hannibal Pump Station and Exborne Tanks, eliminates aging infrastructure and reduces maintenance.

15‐62 – Sixth Avenue Improvements – Abandons 700 LF of cross country 6” – 8” CIP that crosses over an existing creek at two locations and replaces it with a combination of 350 LF 8” and 1,260 LF 10” DIP to relocate the water mains to accessible locations.

15‐63 – Lower Notre Dame Improvements – Replaces 3,400 LF of parallel 6” ‐ 8” CIP with a single 10” DIP to replace aging infrastructure and reduce maintenance.

15‐64 – Tierra Linda Improvements – Installs an in‐line gate valve at Tierra Linda Middle School in order to monitor water quality under an experimental dead‐end scenario.

15‐65 – Folger Drive Improvements – Replaces 830 LF of 6” CIP with 8” / 10” DIP to replace aging infrastructure and improve fire flows.

15‐66 – Vine Street Improvements – Abandons 250 LF of 4” CIP and the Vine Street Regulator, replaces 700 LF of 4” CIP with 6” / 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐67 – Village Drive Area Improvements – Replaces 1,600 LF of 6” CIP with 8” DIP to replace aging infrastructure and eliminate two small dead‐end stubs.

Zone 3

(19 Projects)

15‐09 – Dekoven Tank Utilization Project – A replacement / new installation combination of 2,300 LF of 12” DIP allowing abandonment of two cross country water mains and zone wide fire flow improvement.

15‐10 – Notre Dame Avenue Loop Closure – A replacement / new installation combination of 2,230 LF of 8” DIP to eliminate dead ends, replace aging / undersized infrastructure, and improve fire flows.

15‐11 – Carmelita Avenue Improvements – Replaces 1,300 LF of 4”‐ 6” CIP/PVC with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐12 – Buena Vista Avenue Improvements – Replaces 1,250 LF of 4”‐ 6” CIP/PVC with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐13 – Monroe, Bellemonti, Coronet Avenues Improvements – Replaces 3,200 LF of 4” PVC with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐14 – Mezes Avenue Improvements – Replaces 310 LF of 4” PVC with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐15 – Shirley Road Improvements – A replacement / new installation combination of 720 LF of 8” DIP to eliminate dead ends, replace aging / undersized infrastructure, and improve fire flows.

15‐16 – Williams Avenue, Ridge Road, Hillman Avenue Improvements – A replacement / new installation combination of 2,460 LF of 8” DIP to eliminate dead ends, replace aging / undersized infrastructure, minor zone reconfiguration, and improve fire flows.

15‐17 – Monte Cresta Drive, Alhambra Drive Improvements – Replaces 2,250 LF of 6” CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐18 – Pine Knoll Drive Improvements – Replaces 430 LF of 4” CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐19 – Oak Knoll Drive Improvements –Replaces 920 LF of 4” PVC with 8” DIP, relines or installs 350 LF 8” HDD DIP to reduce a long dead end, replace aging / undersized infrastructure, and improve fire flows.

15‐20 – Thurm and Bettina Avenues Improvements – Replaces 1,150 LF of 4” PVC with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐21 – Lincoln, Monserat Avenues Improvements – Installs 250 LF of 8” DIP with 8” DIP to eliminate two dead ends, creates a loop, and improves fire flows.

15‐22 – Arthur Avenue Improvements – A replacement / new installation combination of 880 LF of 8” DIP to replace aging / undersized infrastructure, eliminate two dead ends between Zone 2 and Zone 3, install a PRV connection between the Zones, and improve fire flows.

15‐24 – San Juan Boulevard Improvements – Abandons 200 LF of 4” CIP paralleling an 8” PVC, replaces 520 LF of 6” CIP with 8” DIP to replace aging / undersized infrastructure, reduce maintenance, and improve fire flows.

15‐30 – Alameda de las Pulgas Improvements – Replaces 1,455 LF of 6” ‐ 8” CIP with 8” DIP to eliminate bottlenecks, replace aging infrastructure prone to breaks, minor reconfigurations to simplify system.

15‐31 – Monserat Avenue Cross Country Abandonment – Abandons 355 LF of 6” CIP to eliminate an inaccessible cross country water main.

15‐89 – Dekoven Tanks Replacement – Replaces the existing 1.0 MG and 0.7 MG originally constructed in 1952 with two 0.8 MG tanks to improve seismic reliability.

15‐90 – Alameda De Las Pulgas Loop Improvements – Installs 1,100 LF of 8” DIP to eliminate two dead ends, creates a loop, and improves water quality.

Zone 4

(1 Project)

15‐08 – Zone 4 Water Main Improvement Project – Replaces 1,300 LF of 4” PVC with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

Zone 5

(7 Projects)

15‐01 – Buckland / Shelford Avenues Improvements – Abandons 270 LF of 6” CIP paralleling a 12” DIP. New connections will be made to the 12” DIP along with other pipe installation to improve fire flows.

15‐02 – Courtland Road Improvements – Replaces 780 LF of 4” – 6” CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐03 – Spring Lane Improvements – Replaces 270 LF of 4” CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐04 – Rose Lane Improvements – Replaces 170 LF of 4” CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐05 – Calwater Intertie – Installs an intertie connection to permit the District the ability to provide water to Calwater in the event of an emergency.

15‐06 – Zone 5 Fire Hydrant Upgrades – Adds 7 hydrants between Desvio Way, Solana Drive and Altura Way improving fire flow protection and flushing operations.

15‐88 – Vine Street Improvements – Replaces 1,400 LF of 6” CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

Zone 6

(1 Project)

15‐07 – Dartmouth Avenue Improvements – Replaces 410 LF of 4” CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

Zone 7

(5 Projects)

15‐25 – Christian Court Improvements – Replaces 300 LF of 4” CIP with 8” DIP and installs an additional fire hydrant to replace aging / undersized infrastructure, improve flushing capabilities, and improve fire flows.

15‐26 – West Belmont Tank Water Main Improvements – A combination of abandonments / replacement / new installation of 1,400 LF of 8” DIP and 2,400 LF of 12” DIP to eliminate cross country and parallel water mains, improve zone wide fire flows, and replace aging infrastructure.

15‐27 – Lassen Drive Improvements – Replaces 1,800 LF of 6” CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐28 – Tahoe Drive Area Improvements – Replaces 900 LF of 4” CIP with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐29 – Belmont Canyon Road Improvements – Replaces 900 LF of 4” – 8” CIP with 8” DIP to eliminate a local bottle neck, replace aging infrastructure, and improve fire flows.

Zone 8

(9 Projects)

15‐32 – Soho Circle Improvements – Replaces 130 LF of 4” PVC with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐33 – Paddington Court Improvements – Replaces 160 LF of 4” PVC with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐34 – Ridgewood Court Improvements – Replaces 200 LF of 4” PVC with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐35 – Bridge Court Improvements – Replaces 280 LF of 4” PVC with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐36 – Parkridge Court Improvements – Replaces 270 LF of 4” PVC with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐37 – Waterloo Court Improvements – Replaces 130 LF of 4” PVC with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐38 – Cliffside Court Improvements – Replaces 330 LF of 4” PVC with 8” DIP to replace aging / undersized infrastructure and improve fire flows.

15‐39 – Zone 8 – 14” Cross Country Improvements – Installs 8 trench dams, 2 remotely controlled gate valves, and a flow meter and/or pressure gauge vault to allow the District to quickly identify a leak along the water main, the ability to isolate a shorter section of repair length.

15‐40 – Hastings Drive Improvements – Replaces 550 LF of 4” CIP/PVC with 8” DIP to replace aging / undersized infrastructure, improve fire flows, and also installs a Zone 8 to Zone 2 jumper to be used in emergency situations.

Zone 9

(0 Projects)

No projects identified in Zone 9.

District Wide Projects

(5 Projects)

15‐83 – Emergency Intertie Rebuilds – Rebuilds / reconfigures the existing interties to obtain more accurate meter readings.

15‐86 – Folger Pump Station Site Demolition – Demolishes the existing pump station building at the abandoned Folger Pump Station.

15‐91 – SCADA System Replacement – Replaces the existing SCADA system.

15‐92 – AMI Installation Completion – Adds automatic meter reading capabilities to each service meter allowing the District and residents to monitor water use remotely.

15‐93 – Dairy Lane Facility Rehabilitation and Improvements – Includes various improvements to the District’s facilities.

View PDF »